施工 最新合同中英文模板-construction-contract

英语建筑施工合同范本Building Construction ContractThis Building Construction Contract (the "Contract") is made and entered into as of [Contract Date] and between [Owner's Name] (the "Owner") and [Contractor's Name] (the "Contractor").1. Project DescriptionThe Contractor shall undertake the construction of a [Building Type] building (the "Project") at the location specified the Owner at [Project Location]. The Project shall include the construction of the building structure, installation of plumbing, electrical, and HVAC systems, and other related works as specified in the architectural and engineering plans and specifications (the "Plans and Specifications") attached hereto as Exhibit A.2. Contract Price and Payment TermsThe total contract price for the Project is [Contract Price] (the "Contract Price"). The Owner shall make the following payments to the Contractor:A deposit of [Deposit Amount] shall be pd within [Deposit Due Date] days after the execution of this Contract.Progress payments shall be made based on the pletion of certn milestones as set forth in the Payment Schedule attached hereto as Exhibit B.The final payment of [Final Payment Amount] shall be made upon the substantial pletion of the Project and after the Owner has inspected and accepted the work.3. Construction ScheduleThe Contractor shall mence the construction work on or before [Commencement Date] and shall plete the Project on or before [Completion Date]. The Contractor shall submit a detled construction schedule to the Owner within [Schedule Submission Date] days after the execution of this Contract. The construction schedule shall be updated the Contractor on a regular basis to reflect the actual progress of the work.4. Changes and Extra WorkAny changes or additions to the Plans and Specifications or any extra work required the Owner shall be subject to a written change order. The change order shall specify the nature and extent of the change, the additional cost (if any), and the impact on the construction schedule. The Contractor shall not proceed with any change or extra work without the prior written approval of the Owner.5. WarrantyThe Contractor warrants that the work performed under this Contract shall be free from defects in materials and workmanship for a period of [Warranty Period] from the date of substantial pletion of the Project. During the Warranty Period, the Contractor shall be responsible for correcting any defects at no additional cost to the Owner.6. Insurance and BondsThe Contractor shall obtn and mntn at its own expense the following insurance policies:Workers' Compensation Insurance as required law.General Liability Insurance with a minimum coverage of [Liability Insurance Amount].Builder's Risk Insurance to cover the Project during the construction period.The Contractor shall also provide a performance bond and a payment bond in the amounts specified in the Contract Documents.7. TerminationEither party may terminate this Contract in the event of a material breach the other party. In the event of termination, the Contractor shall be end to payment for work performed up to the date of termination, less any damages or costs incurred the Owner as a result of the Contractor's breach.8. Dispute ResolutionAny disputes arising out of or in connection with this Contract shall be resolved through arbitration in accordance with the rules of the [Arbitration Institution]. The arbitration shall take place in [Arbitration Location].9. Governing LawThis Contract shall be governed and construed in accordance with the laws of [Jurisdiction].10. Entire AgreementThis Contract constitutes the entire agreement between the parties and supersedes all prior negotiations, representations, and agreements. No modification or amendment of this Contract shall be effective unless in writing and signed both parties.IN WITNESS WHEREOF, the parties have executed this Contract as of the date first above written.[Owner's Signature] [Owner's Name] [Owner's Address] [Owner's Contact Information][Contractor's Signature] [Contractor's Name] [Contractor's Address] [Contractor's Contact Information]Please note that this is a basic template and may need to be customized to meet the specific requirements of your project. It is remended that you consult with a legal professional before entering into any construction contract.。

建筑施工英文合同范本（CONSTRUCTION CONTRACT）甲方（Party A）：____________________________地址（Address）：____________________________电话（Tel）：____________________________法定代表人（Legal Representative）：____________________________乙方（Party B）：____________________________地址（Address）：____________________________电话（Tel）：____________________________法定代表人（Legal Representative）：____________________________鉴于甲方拟在____________（项目地点）建设____________（项目名称），并已通过招标或其他方式确定乙方为该项目的施工方，甲乙双方经友好协商，达成如下协议：第一条工程概况1. 工程名称：____________________________2. 工程地点：____________________________3. 工程内容：____________________________4. 工程承包范围：____________________________第二条工程期限1. 开工日期：______年______月______日2. 竣工日期：______年______月______日3. 总工期：______日历天第三条工程质量标准本工程质量标准为____________________________。

第四条合同价款及支付方式1. 合同价款为人民币（大写）：____________________________元整（小写：￥__________元），此价款为固定总价，不因任何因素而调整。

建筑施工合同范本英语Building Construction Contract范本PART 1: GENERAL PROVISIONSContract Number: [具体合同编号]Date: [签订日期]This Building Construction Contract (hereinafter referred to as "the Contract") is made and entered into between:Party A (the Employer):Name: [甲方名称]Address: [甲方地址]Contact Person: [甲方联系人]Contact Information: [甲方联系电话等]Party B (the Contractor):Name: [乙方名称]Address: [乙方地址]Contact Person: [乙方联系人]Contact Information: [乙方联系电话等]PART 2: PROJECT DESCRIPTION1. Project Name: [项目名称]2. Project Location: [项目地点]3. Project Scope: [详细描述项目范围，包括但不限于工程内容、工程规模等]PART 3: CONTRACT PRICE AND PAYMENT1. The total contract price for the Project is [具体金额].2. Payment terms and methods shall be stipulated in accordance with the agreed schedule.PART 4: CONSTRUCTION PERIODThe construction period of the Project starts from [起始日期] and is expected to be pleted within [预计完工日期].PART 5: QUALITY REQUIREMENTSThe Contractor shall ensure that the construction work meets the relevant national and industry standards and quality requirements.PART 6: SAFETY AND ENVIRONMENTAL PROTECTIONBoth parties shall jointly ensure the safety and pliance with environmental protection regulations during the construction process.PART 7: WARRANTY AND LIABILITYThe Contractor shall provide a certn warranty period for the pleted project and be liable for any defects or damages caused during the warranty period.PART 8: DISPUTE RESOLUTIONIn case of disputes arising during the performance of the Contract, the parties shall first attempt to resolve them through negotiation. If negotiation fls, the disputes may be submitted to arbitration or litigation in accordance with the relevant laws and regulations.PART 9: OTHER TERMSOther terms and conditions such as contract termination, amendment, and force majeure events shall also be clearly stipulated in the Contract.Both parties sign and seal this Contract in duplicate, each party holding one copy, with the same legal effect.Party A (Employer): [甲方盖章]Party B (Contractor): [乙方盖章]Contact Person: [甲方代表签字]Contact Person: [乙方代表签字]。

建筑施工合同范本英语Construction Contract TemplateThis Construction Contract (the "Contract") is made and entered into as of ____________ (the "Effective Date"), and between ____________ ("Owner"), with a ing address of ____________, and ____________ ("Contractor"), with a ing address of____________.WHEREAS, Owner desires to construct a building or structure (the "Project") on the property located at ____________ (the "Property"), and Owner desires to engage Contractor to perform the construction work for the Project; and WHEREAS, Contractor is willing to perform the construction work for the Project in accordance with the terms and conditions set forth in this Contract.NOW, THEREFORE, in consideration of the mutual covenants and agreements set forth herein, and for other good and valuable consideration, the receipt and sufficiency of which are here acknowledged, the parties agree as follows:1. Scope of Work. Contractor shall perform the construction work for the Project in accordance with the plans and specifications attached hereto as Exhibit A (the "Plans and Specifications"). Contractor shall be responsible for providing all labor, materials, equipment, and other services necessary to plete the Project in a good and workmanlike manner.2. Contract Price. The total contract price for the Project shall be ____________ (the "Contract Price"). The Contract Price shall include all labor, materials, equipment, and other services necessary to plete the Project in accordance with the Plans and Specifications.3. Payment Terms. Payment for the Project shall be made in accordance with the following schedule:(a) Initial Payment: Upon execution of this Contract, Owner shall pay Contractor an initial payment of ____________ (the "Initial Payment").(b) Progress Payments: Thereafter, on a monthly basis, Contractor shall submit a request for payment for the work performed during the precedingmonth. The request for payment shall include a statement of the work performed, the costs incurred, and the percentage of pletion of the Project. Owner shall pay Contractor the amount requested within ____________ days after receipt of the request for payment.(c) Final Payment: Upon substantial pletion of the Project, Contractor shall submit a final request for payment. The final request for payment shall include a statement of the work performed, the costs incurred, and the percentage of pletion of the Project. Owner shall pay Contractor the remning balance of the Contract Price within ____________ days after receipt of the final request for payment.4. Time of Completion. Contractor shall plete the Project in accordance with the construction schedule attached hereto as Exhibit B (the "Construction Schedule"). Time is of the essence with respect to the pletion of the Project. If Contractor fls to plete the Project the pletion date set forth in the Construction Schedule, Contractor shall pay Owner a penalty of ____________ per day for each day of delay.5. Changes to the Project. Owner may request changes to the Project at any time during the course of the construction work. Any changes requested Owner shall be in writing and shall include a description of the requested change and the impact of the change on the Contract Price and the Construction Schedule. Contractor shall provide Owner with a written estimate of the additional costs and time required to implement the requested change. If Owner approves the requested change, the Contract Price and the Construction Schedule shall be amended accordingly.6. Warranty. Contractor warrants that the Project will be free from defects in materials and workmanship for a period of ____________ years after the date of substantial pletion of the Project. If any defects in materials or workmanship arise during the warranty period, Contractor shall, at its own expense, repr or replace the defective materials or workmanship.7. Indemnification. Contractor shall indemnify and hold harmless Owner from and agnst any and all clms, losses, damages, liabilities, and expenses (includingreasonable attorneys' fees and costs) arising out of or relating to the performance of the construction work Contractor or its employees, subcontractors, or agents.8. Insurance. Contractor shall mntn mercial general liability insurance in an amount not less than ____________ per occurrence and workers' pensation insurance in accordance with applicable law. Upon request, Contractor shall provide Owner with proof of such insurance.9. Termination. Either party may terminate this Contract for convenience upon written notice to the other party. If Owner terminates this Contract for convenience, Owner shall pay Contractor for the work performed and the costs incurred up to the date of termination. If Contractor terminates this Contract for convenience, Contractor shall be liable for any additional costs incurred Owner to plete the Project.10. Governing Law. This Contract shall be governed and construed in accordance with the laws of the state of ____________.11. Dispute Resolution. Any disputes arising out of or relating to this Contract shall be resolved through binding arbitration in accordance with the rules of the American Arbitration Association. The decision of the arbitrator shall be final and binding upon the parties.12. Entire Agreement. This Contract constitutes the entire agreement between the parties with respect to the subject matter hereof and supersedes all prior agreements。

施工合同范本英文版This Construction Contract ("Contract") is entered into on [insert date] by and between [Contractor Name], a company organized and existing under the laws of [insert jurisdiction], with its principal place of business at [Contractor Address], and [Owner Name], a company organized and existing under the laws of [insert jurisdiction], with its principal place of business at [Owner Address].1. Scope of Work: Contractor agrees to perform the construction work described in the project plans and specifications ("Work") at [Project Location]. The Work includes [describe in detail the scope of work to be performed].2. Time of Completion: Contractor agrees to complete the Work in a timely manner and in accordance with the schedule set forth in the project plans and specifications. Any delays in completion beyond the agreed-upon schedule shall be documented and agreed upon in writing by both parties.3. Payment: Owner agrees to pay Contractor the total contract price of [insert total contract price] for the completion of the Work. Payments shall be made in installments as follows: [insert payment schedule]. Owner shall make payments to Contractor within [insert number] days of receipt of an invoice.4. Changes: Any changes to the scope of work, specifications, or materials must be agreed upon in writing by both parties and may result in additional costs and/or time for completion.5. Insurance: Contractor shall maintain appropriate insurance coverage throughout the duration of the project, including but not limited to general liability insurance and workers' compensation insurance.6. Warranties: Contractor warrants that all work performed under this Contract shall be in accordance with industry standards and free from defects in workmanship and materials for a period of [insert warranty period].7. Termination: Either party may terminate this Contract upon written notice if the other party materially breaches any of its obligations under this Contract and fails to cure such breach within [insert cure period] days of receipt of written notice.8. Governing Law: This Contract shall be governed by the laws of [insert governing jurisdiction].IN WITNESS WHEREOF, the parties hereto have executed this Contract as of the date first above written.[Contractor Name]By: ________________________________Title: _______________________________ [Owner Name]By: ________________________________ Title: _______________________________ Date: _______________________________。

**Construction Contract**This Construction Contract (the "Contract") is made and entered into as of [Insert Date], by and between [Insert Contractor's Name], hereinafter referred to as the "Contractor," and [Insert Client's Name], hereinafter referred to as the "Client."**Recitals**WHEREAS, the Client desires to have certain construction services performed by the Contractor;WHEREAS, the Contractor is willing to perform such construction services upon the terms and conditions set forth herein;NOW, THEREFORE, in consideration of the mutual promises contained herein, the parties hereto agree as follows:**Article 1: Scope of Work**1.1 The Contractor agrees to perform all construction services necessary to complete the construction of [Insert Project Name] (the "Project") in accordance with the plans and specifications provided by the Client.1.2 The Contractor shall complete the Project within [Insert Completion Date], subject to any delays caused by Force Majeure events as definedin Article 12 of this Contract.**Article 2: Price and Payment Terms**2.1 The Contractor shall provide the Client with a detailed breakdown of the total cost of the Project, including labor, materials, equipment,and any other expenses (the "Price"). The Price shall be set forth inthe attached Schedule A.2.2 The Client shall pay the Contractor the Price for the completion of the Project, less any retainage as may be specified in Article 4 of this Contract, upon the satisfaction of the Contractor's performance of the Services.2.3 Payment shall be made by the Client to the Contractor in accordance with the payment schedule set forth in the attached Schedule B.**Article 3: Performance of Services**3.1 The Contractor shall perform the Services with reasonable care and skill, and in accordance with all applicable laws, regulations, and industry standards.3.2 The Contractor shall be responsible for the coordination and management of all subcontractors and suppliers involved in the performance of the Services.3.3 The Contractor shall provide the Client with regular updates on the progress of the Project, including but not limited to, weekly progress reports and milestone notifications.**Article 4: Retainage**4.1 The Client shall withhold a certain percentage of the Price as retainage ("Retainage") to ensure the satisfactory completion of the Project. The amount of Retainage shall be specified in the attached Schedule C.4.2 The Contractor shall be entitled to receive payment of the Retainage upon the satisfactory completion of the Project, as determined by the Client in its sole discretion.**Article 5: Default and Termination**5.1 If either party defaults in the performance of any material obligation provided in this Contract and such default continues for a period of [Insert Number] days after written notice thereof from the other party, the non-defaulting party may terminate this Contract by written notice to the defaulting party.5.2 In the event of termination, the Client shall be liable to pay the Contractor for any Services performed and expenses incurred up to the date of termination.**Article 6: Dispute Resolution**6.1 Any disputes arising out of or in connection with this Contractshall be referred to and finally resolved by arbitration in accordance with the rules of the [Insert Arbitration Association].6.2 The decision of the arbitrator(s) shall be final and binding upon the parties hereto, and judgment upon the award rendered by the arbitrator(s) may be entered in any court having jurisdiction thereof.**Article 7: Indemnification**7.1 The Contractor shall indemnify and hold harmless the Client against any and all claims, losses, damages, liabilities, and expenses (including but not limited to attorney's fees and court costs) arising out of or in connection with the performance of the Services.**Article 8: Governing Law and Jurisdiction**8.1 This Contract shall be governed by and construed in accordance with the laws of [Insert Jurisdiction].8.2 Any legal action or proceeding arising out of or in connection with this Contract shall be brought exclusively in the courts of [Insert Jurisdiction], and both parties hereby consent to the jurisdiction of such courts.**Article 9: Entire Agreement**9.1 This Contract constitutes the entire agreement between the parties with respect to the subject matter hereof and supersedes all prior agreements, understandings, negotiations, and discussions, whether oral or written, of the parties.**Article 10: Amendments**10.1 This Contract may be amended or modified only by a written instrument executed by both parties.**Article 11: Notices**11.1 All notices, requests, demands, and other communications under this Contract shall be in writing and shall be deemed to have been duly givenon the date of service if served personally on the party to whom notice is to be given, or on the third day after mailing if mailed to the party to whom notice is to be given, by first class mail, registered or certified, postage prepaid, and properly addressed as follows:To the Contractor:[Insert Contractor's Address]To the Client:[Insert Client's Address]**Article 12: Force Majeure**12.1 The parties agree that neither party shall be liable for anyfailure or delay in the performance of its obligations under this Contract due to any cause beyond its reasonable control, including but not limited to acts of God, labor disputes, or disruptions in transportation, provided that the affected party promptly notifies the other party of the existence and nature of such cause.**Schedule A: Detailed Breakdown of Price**[Attach detailed breakdown of the total cost of the Project, including labor, materials, equipment, and any other expenses]**Schedule B: Payment Schedule**[Attach payment schedule, including percentage of completion and corresponding payment amounts]**Schedule C: Retainage Amount**[Attach amount of Retainage to be withheld from the final payment]IN WITNESS WHEREOF, the parties have executed this Construction Contract as of the date first above written.[Insert Client's Name]By: ___________________________Name:Title:[Insert Contractor's Name]By: ___________________________ Name:Title:。

资料可以编辑修改使用资料可以编辑修改使用资料可以编辑修改使用致力于数据挖掘，合同简历、论文写作、PPT设计、计划书、策划案、学习课件、各类模板等方方面面，打造全网一站式需求主要经营：网络软件设计、图文设计制作、发布广告等，公司秉着以优质的服务对待每一位客户，做到让客户满意Construction Contract工程合同PO No.: XXXXXXXBuyer:. Date of signature:甲方:签约日期：Seller:乙方:This Purchase Order is made by and between the Buyer and the Seller: Whereby the Buyer agrees to buy and the Seller agrees to sell the under mentioned commodity according to the terms and conditions stipulated below:甲乙双方经友好协商，一致就供应下列产品，达成如下条款：1. Scope of Supply and Price工作范围及价格明细2. Technical Requirement, Quality Requirement, Standard & Warranty Period:Seller shall carried out the construction in strict accordance with the National Standard and the requirements stipulated in the Technical Agreement No. ________which both party signed (see attached documents). The warranty period shall be 1 year after placement of Goods in service.技术要求、质量要求、技术标准和质保期限: 按国家标准和双方签定的技术协议（编号：______见附件）施工，质保期为投产后1年。

建筑施工合同范本英语Construction Contract TemplateThis Construction Contract ("Contract") is made and entered into as of [date] and between [Party A Name], a [Party A Entity Type] with its principal place of business at [Party A Address] ("Party A"), and [Party B Name], a [Party B Entity Type] with its principal place of business at [Party B Address] ("Party B").1. Project DescriptionParty A intends to undertake a construction project ("Project") at [Project Location], and Party B has the necessary qualifications, experience, and capabilities to perform the construction work. The Project shall include, but not be limited to, [Describe the scope of work].2. Contract Price and Payment Terms2.1 The total contract price for the Project is [Contract Price] (inclusive of all taxes and fees).2.2 Party A shall make the following payments to Party B:[Payment Schedule and Amounts]2.3 Payments shall be made within [Number of Days] days after Party A receives the invoice from Party B and after the relevant milestone or work has been pleted and approved Party A.3. Project Schedule3.1 The Project shall mence on [Commencement Date] and shall be pleted [Completion Date].3.2 Party B shall submit a detled project schedule to Party A within [Number of Days] days after the execution of this Contract. The project schedule shall include the start and pletion dates of each phase of the Project and the key milestones.3.3 Party B shall make every effort to meet the project schedule. In the event of any delay, Party B shall promptly notify Party A and provide a revised project schedule and an explanation for the delay.4. Workmanship and Materials4.1 Party B shall perform the construction work in a professional and workmanlike manner, in accordance with the industry standards and best practices.4.2 Party B shall use only high-quality materials that are in accordance with the specifications and requirements of the Project. All materials used in the Project shall be subject to Party A's approval.5. Inspection and Acceptance5.1 Party A or its representatives shall have the right to inspect the progress and quality of the work at any time during the construction period.5.2 Upon pletion of the Project, Party B shall notify Party A in writing of the pletion. Party A shall conduct an inspection of the Project within [Number of Days] days after receiving the notice. If the Project is found to be in accordance with the requirements of this Contract, Party A shall issue a written acceptance certificate.5.3 In the event that the Project is not in accordance with the requirements of this Contract, Party A shall notify Party B in writing of the deficiencies. Party B shall rectify the deficiencies within [Number of Days] days after receiving the notice.6. Warranties6.1 Party B warrants that the construction work and materials used in the Project shall be free from defects in workmanship and materials for a period of [Warranty Period] from the date of acceptance.6.2 In the event of any defects or deficiencies during the warranty period, Party B shall be responsible for rectifying the same at no additional cost to PartyA.7. Force Majeure7.1 If either party is unable to perform its obligations under this Contract due to an event of force majeure, such as natural disasters, wars, strikes, or government actions, the affected party shall notify the other party in writing as soon as possible and provide evidence of the force majeure event.7.2 The performance of the obligations under this Contract shall be suspended for the duration of the force majeure event. If the force majeure event continues for more than [Number of Days] days, either party may terminate this Contract.8. Termination8.1 Either party may terminate this Contract in the event of a material breach of this Contract the other party. A material breach shall include, but not be limited to, flure to perform the obligations under this Contract, flure to meet the project schedule, or flure to ply with the quality standards.8.2 In the event of termination, the parties shall settle the accounts in accordance with the provisions of this Contract.9. Dispute Resolution9.1 Any dispute or controversy arising out of or in connection with this Contract shall be resolved through friendly negotiation between the parties. If the parties are unable to resolve the dispute through negotiation within [Number of Days] days, the dispute shall be submitted to arbitration in accordance with the rules of [Arbitration Institution].9.2 The arbitration award shall be final and binding on both parties.10. Miscellaneous10.1 This Contract constitutes the entire agreement between the parties and supersedes all prior negotiations, representations, and agreements.10.2 This Contract shall be governed and construed in accordance with the laws of [Jurisdiction].10.3 Any amendment or modification to this Contract shall be in writing and signed both parties.IN WITNESS WHEREOF, the parties have executed this Contract as of the date first above written.Party A: [Party A Name]Signature: [Party A Signature]Date: [Date]Party B: [Party B Name]Signature: [Party B Signature] Date: [Date]。

第1篇Contract No.: [Contract Number]Date: [Contract Date]Parties Involved:1. Contractor:- Name: [Contractor's Name]- Address: [Contractor's Address]- Contact Person: [Contractor's Contact Person]- Contact Information: [Contractor's Contact Information]2. Client:- Name: [Client's Name]- Address: [Client's Address]- Contact Person: [Client's Contact Person]- Contact Information: [Client's Contact Information]Scope of Work:1. Project Description: [Detailed description of the construction project, including type of project, location, and main objectives.]2. Work to be Performed: [List of all the specific tasks and activities to be carried out by the Contractor, including design, construction, and any other related services.]3. Deliverables: [Detailed list of all deliverables, including but not limited to drawings, specifications, progress reports, and final certificates of completion.]Contract Price and Payment Terms:1. Contract Price: [Total contract price including all costs, fees, and expenses.]2. Payment Schedule:- Progress Payments: [Details of progress payments, including payment milestones, percentage of work completed, and payment schedule.]- Final Payment: [Conditions and terms for the final payment, including completion and final inspection requirements.]3. Retention: [Percentage of the contract price to be retained until the project is completed and all conditions are met.]Duration of the Contract:1. Start Date: [Date when the work is to begin.]2. Completion Date: [Estimated completion date based on the project scope and schedule.]3. Extension of Time: [Conditions under which the completion date may be extended and the process for requesting an extension.]Quality Standards:1. Quality Requirements: [Specific quality standards to be adhered to during the construction process, including materials, workmanship, and compliance with relevant codes and regulations.]2. Inspection and Testing: [Provisions for regular inspections and testing to ensure compliance with quality standards.]Warranties and Liabilities:1. Warranties: [Details of warranties provided by the Contractor, including duration and scope of warranty coverage.]2. Liabilities: [Responsibilities and liabilities of the Contractor in the event of any defects, damages, or claims arising from the work performed under the contract.]Force Majeure:1. Definition: [Definition of force majeure events, including acts of God, war, strikes, labor disputes, and any other events beyond the reasonable control of the Contractor.]2. Effect: [Provisions regarding the suspension of the contract and the obligations of the parties in the event of a force majeure event.]Dispute Resolution:1. Arbitration: [Provisions for resolving disputes, including the procedure for arbitration and the appointment of an arbitrator.]2. Legal Actions: [Conditions under which legal actions may be taken and the jurisdiction of any disputes.]General Provisions:1. Governing Law: [The laws of the jurisdiction that will govern the interpretation and enforcement of the contract.]2. Amendments: [Provisions regarding the process for making amendments to the contract.]3. Termination: [Conditions under which the contract may be terminated and the consequences of termination.]Acknowledgment:The parties hereto acknowledge that they have read, understand, and agree to be bound by the terms and conditions of this Construction Engineering Contract.---Contract No.: [Contract Number]Date: [Contract Date]Contractor:[Signature of Contractor] ___________________________[Name of Contractor] ___________________________Client:[Signature of Client] ___________________________[Name of Client] ___________________________---Note: This is a general template for a construction engineering contract. Specific contracts may require additional details or clauses based onthe nature of the project and the requirements of the parties involved.It is recommended that legal advice be sought when drafting or entering into a construction contract.第2篇Contract No. __________Contract Date: __________Contractor: __________Client: __________1. IntroductionThis Construction Engineering Contract (hereinafter referred to as "the Contract") is entered into between __________ (hereinafter referred toas "the Contractor") and __________ (hereinafter referred to as "the Client") on the basis of mutual consultation, agreement, and mutual benefit. The Contractor agrees to construct and complete theconstruction project as specified in the Contract, and the Client agrees to pay the agreed contract price for the completed construction project. The Contract is binding on both parties and shall be strictly observed.2. Project Description2.1 Project Name: __________2.2 Project Location: __________2.3 Project Scope: The construction project includes the following scopes:a. Civil engineering works: __________b. Electrical engineering works: __________c. Mechanical engineering works: __________d. Other relevant works: __________3. Contract Price3.1 The total contract price for the construction project is __________ Yuan, which is subject to the following terms:a. The Contractor shall provide detailed project estimates and invoices for the Client's approval.b. The Client shall make payment in accordance with the agreed payment schedule.c. Any additional costs due to changes in the project scope or unforeseen circumstances shall be agreed upon by both parties in writing.4. Performance and Quality4.1 The Contractor shall ensure that the construction project is completed within the agreed time frame and meets the quality standards specified in the Contract.4.2 The Contractor shall adhere to the relevant national standards,local regulations, and industry practices during the construction process.4.3 The Client shall have the right to inspect and accept the construction project at any time during the construction process.5. Payment Schedule5.1 The payment schedule is as follows:a. Upon the signing of the Contract, the Client shall pay the Contractor a deposit of __________ Yuan.b. Upon the completion of each phase of the project, the Contractor shall submit an invoice to the Client for payment.c. The Client shall pay the invoice within __________ days upon receipt.6. Insurance6.1 The Contractor shall obtain and maintain all necessary insurance policies to cover the risks associated with the construction project, including but not limited to:a. Public liability insuranceb. Workers' compensation insurancec. Property insurance7. Termination of the Contract7.1 Either party may terminate the Contract in writing if the other party fails to comply with the terms and conditions of the Contract.7.2 Upon termination of the Contract, the Contractor shall immediately cease all construction activities and the Client shall pay the Contractor for the work completed up to the date of termination.8. Dispute Resolution8.1 Any disputes arising from the execution of the Contract shall be settled through friendly negotiations between the parties.8.2 If the parties fail to reach an agreement through negotiations, the dispute shall be submitted to the relevant arbitration commission for resolution.9. Governing LawThis Contract shall be governed by the laws of __________.10. Final Provisions10.1 This Contract constitutes the entire agreement between the parties and supersedes all prior agreements and understandings, whether written or oral.10.2 Any amendment or modification of this Contract shall be effective only if it is in writing and signed by both parties.Contractor Signature: ___________________________Client Signature: ___________________________Date: ___________________________---Construction Engineering ContractContract No. __________Contract Date: __________Contractor: __________Client: __________1. Introduction本建筑工程合同（以下简称“本合同”）由__________（以下简称“承包商”）与__________（以下简称“业主”）在相互协商、一致同意和互惠互利的基础上签订。

施工合同中英文合同范本CONSTRUCTION CONTRACTThis Construction Contract (the "Contract") is made and entered into as of the _____ day of ______, 20__, by and between:[Company Name], a [State] corporation with its principal place of business at [Address] (hereinafter referred to as "Owner"), and[Contractor Name], a [State] corporation with its principal place of business at [Address] (hereinafter referred to as "Contractor").WHEREAS, the Owner desires to engage the Contractor to perform certain construction work, and the Contractor is willing to perform such work upon the terms and conditions set forth herein.NOW, THEREFORE, in consideration of the mutual promises and covenants contained herein and other good and valuable consideration, the receipt and sufficiency of which are hereby acknowledged, the parties agree as follows:1. SCOPE OF WORKThe Contractor shall perform the construction work (the "Work") as described in the attached specifications (the"Specifications") and in accordance with the drawings and plans attached hereto (the "Plans").2. CONTRACT PRICEThe total price for the Work shall be [$_____] (the "Contract Price"), which shall be paid by the Owner to the Contractorin accordance with the payment schedule set forth in Exhibit A.3. PERFORMANCE PERIODThe Work shall commence on the _____ day of ______, 20__, and shall be completed by the _____ day of ______, 20__ (the "Completion Date").4. CHANGE ORDERSAny changes to the Work shall be documented in writing and signed by both parties (a "Change Order"). The Contractor shall provide a revised estimate of the Contract Price for any Change Order.5. WARRANTYThe Contractor warrants that all Work will be performed in a good and workmanlike manner and will conform to the Specifications and Plans. The warranty period shall be [___] years from the date of Substantial Completion.6. DEFAULTIf either party defaults in the performance of any of its obligations under this Contract, the non-defaulting party may terminate this Contract upon written notice and may pursue any and all legal remedies available.7. DISPUTE RESOLUTIONAny disputes arising out of or in connection with this Contract shall be resolved by arbitration in accordance with the rules of the American Arbitration Association.8. ASSIGNMENTThis Contract and the rights and obligations hereunder may not be assigned by either party without the prior written consent of the other party, except that the Owner may assign this Contract to a subsequent owner of the property.9. NOTICESAll notices required or permitted under this Contract shall be in writing and shall be deemed given when delivered personally or by overnight courier or mailed by registered or certified mail, return receipt requested, to the addresses set forth above or to such other address as either party may designate in writing.10. GOVERNING LAWThis Contract shall be governed by and construed in accordance with the laws of the State of [State].11. ENTIRE AGREEMENTThis Contract, including all exhibits and attachments hereto, constitutes the entire agreement between the parties and supersedes all prior negotiations, representations, and understandings between the parties.12. AMENDMENTSThis Contract may be amended only in writing signed by both parties.IN WITNESS WHEREOF, the parties have executed this Contract as of the date first above written.[Owner's Name] [Contractor's Name]By: _______________________ By: _______________________ [Title] [Title][Date] [Date]EXHIBIT APayment Schedule1. A deposit of [___%] of the Contract Price shall be paid upon execution of this Contract.2. Progress payments shall be made as follows:- [___%] upon completion of [milestone].- [___%] upon completion of [milestone].- [___%] upon substantial completion of the Work.3. The final payment, including any retention, shall be made upon final completion and acceptance of the Work.(The rest of this page is intentionally left blank)[Signature Page]。