景观工程设计合同中英文(1)

合同编号：Project No.XX第五园七期景观工程设计合同XX Large phase II project Landscape Design Service Agreement项目名称：XX第五园七期项目建设地点：中国设计内容：景观设计合同委托方(甲方)：市XX南城房地产有限公司承接方(乙方)：Karl Princic Design/Intaran Design Inc签订日期：年月Project Name：VANKE XX SHENZHENProject Location：SHENZHEN CHINADesign Content：LANDSCAPE DESIGN SERVICEParty A：SHENZHEN VANKE XINGYE REAL ESTATE CO. LTD.,Party B：Karl Princic Design/Intaran Design Inc Execution Date:目录CATALOGUE1. 合同依据2. 项目概况3. 设计依据4. 设计范围5. 双方权利义务6. 费用、付款及设计成果7. 违约责任8. 合同生效、终止及结束9. 一般条款1. Bases of the Agreement2. General Description of the Project3. Bases of the Design4. Scope of the Design5. Rights and Obligations6. Fees, Payment and Delivery of Documents7. Liability for Breach of the Agreement8. Execution and Termination9. Miscellaneous1：合同依据合同与下列法律条款一致：1.1 《中华人民共和国合同法》、《中华人民共和国建筑法》1.2 《建设工程勘查设计市场管理规定》及其它有关建筑工程勘察设计的管理法规和规章。

设计施工合同（中英对照）合同编号：____________签订日期：____年__月__日甲方（委托方）：____________乙方（受托方）：____________根据《中华人民共和国合同法》、《中华人民共和国建筑法》、《中华人民共和国民法典》以及其他有关法律法规的规定，甲乙双方在平等、自愿、公平、诚信的原则基础上，就甲方委托乙方进行设计施工的事宜，达成如下协议：一、项目概述1.1 项目名称：____________1.2 项目地点：____________1.3 项目内容：____________二、设计施工范围及要求2.1 乙方根据甲方的委托，负责完成项目的初步设计、施工图设计、施工组织设计等工作。

2.2 乙方应按照甲方的要求和相关法律法规的规定，确保设计施工的质量、安全、进度和投资控制等目标的实现。

2.3 乙方应提供设计施工所需的所有技术文件和施工图纸，并保证其真实、完整、准确。

2.4 乙方应按照合同约定的时间和质量要求，完成设计施工任务。

三、合同价格及支付方式3.1 乙方向甲方提供的设计施工服务，合同总价为人民币（大写）：____________元整（小写）：____________元。

3.2 甲方支付乙方设计施工费用的进度，按照双方约定的时间节点进行。

3.3 甲方支付乙方设计施工费用的方式，采取以下第____________种方式：（1）一次性支付：甲方在合同签订后____个工作日内，向乙方支付合同总价。

（2）分期支付：甲方在设计施工进度达到约定的节点后，向乙方支付相应的设计施工费用。

四、合同履行及验收4.1 乙方应按照合同约定的时间节点，向甲方提交设计施工成果。

4.2 甲方应按照合同约定的时间节点，对乙方提交的设计施工成果进行验收。

4.3 甲方对乙方提交的设计施工成果验收不合格的，乙方应按照甲方的要求进行整改，并重新提交。

4.4 甲方对乙方提交的设计施工成果验收合格的，甲方应向乙方支付合同约定的设计施工费用。

工程设计委托合同（中英文）CONTRACT FOR CONSTRUCTION DESIGN客户方：设计方：双方本着公平、自愿和诚信的原则，经友好协商达成如下条款（包括基本条款以及其他条款两个部分）： Under the principles of fairness, free will and good will, IT IS HEREBY AGREED between both parties as follows (the Contract includes two parts, i.e. the General Articles and the Contingent Articles):-1.客户方委托设计方提供的建筑设计服务均以本合同各项条款、附录、附表以及双方为履行本合同相关内容所签订的补充协议等所约定的内容为准，设计方应按照双方的约定和客户方的要求完成― A‖工程设计的各项工作。

本合同的附录、附表、其他条款以及补充协议等附件是本合同不可分割的部分，具有与本协定书同等的法律效力。

The architectural design services that the Client appoints the Designer to provide shall be in compliance with the provisions, appendixes and exhibits of the Contract, as well as with the provisions in the supplementary agreements in conjunction with the execution of the Contract that have entered or may be entered between the parties. The Designer shall carry out the design tasks for ―A‖ Project according to the agreement between both parties as well as the requirements of the Client. Appendixes, exhibits, other articles and supplementary agreements of the Contract are integral part of the Contract, and shall have the same legal binding force with the Contract.2.客户方委托设计方为― A‖工程提供的详细设计服务项目全部列于本合同附表2——《设计服务项目清单》中，同时设计方承诺按照该附表中客户方的要求提供列明的全部服务项目。

Engineering Design Contract Template(1) Engineer. The Engineer is [Engineer's Name], a professional engineer licensed in [State/Province], with a primary place of business at [Engineer's Address].(2) Client. The Client is [Client's Name], a [type of business entity], with a primary place of business at [Client's Address].(3) The Engineer and the Client (collectively referred to as the "Parties") hereby enter into this Engineering Design Contract (the "Contract") effective as of [Effective Date].1. ServicesThe Engineer agrees to provide the following services to the Client (the "Services"):(a) Design Services. The Engineer will provide architectural and engineering design services for the [Project Name], located at [Project Location], in accordance with the project scope, specifications, and requirements as provided by the Client from time to time.(b) Consulting Services. The Engineer may also provide consulting services related to the Services, including but not limited to,technical advice, project management, and coordination of subcontractors and consultants.2. Scope of WorkThe Engineer will perform the Services in accordance with the following scope of work:(a) Project Design. The Engineer will develop and prepare the project design documents, including plans, specifications, calculations, and other technical drawings, in accordance with applicable codes, standards, and regulations.(b) Project Coordination. The Engineer will coordinate with the Client, subcontractors, consultants, and other professionals involved in theproject to ensure timely completion and compliance with the project requirements.(c) Permit Applications. The Engineer will assist the Client in obtaining all necessary permits, approvals, and authorizations from relevant authorities for the project.(d) Construction Observation. The Engineer may provide construction observation services to ensure that the work is performed in accordance with the design documents and specifications.3. TermThe term of this Contract shall commence on the Effective Date and continue until the completion of the Services. The Engineer agrees to complete the Services within [Project Completion Date], subject to any delays or extensions as agreed by the Parties.4. CompensationThe Client agrees to compensate the Engineer for the Services as follows:(a) Fixed Fee. The Client shall pay the Engineer a fixed fee of [Fixed Fee Amount] for the completion of the Services. The fixed fee shall be inclusive of all design work, consulting services, and other related activities performed by the Engineer.(b) Additional Services. The Engineer may provide additional services at the Client's request that are not within the original scope of work. The Client agrees to pay the Engineer's hourly rate of [Hourly Rate] for such additional services.(c) Expenses. The Engineer may incur certain expenses in connection with the performance of the Services, including but not limited to, printing costs, travel expenses, and consultant fees. The Client agrees to reimburse the Engineer for all reasonable and properly documented expenses upon submission of detailed invoices.5. Payment TermsThe Client agrees to make payments to the Engineer in accordance with the following terms:(a) Advance Payment. The Client shall pay the Engineer an advance payment of [Advance Payment Percentage] of the fixed fee within [Advance Payment Due Date] as a deposit to cover initial design and consulting costs.(b) Progress Payments. The Client shall make progress payments to the Engineer in installments based on the completion of milestones or phases of the Services, as agreed by the Parties.(c) Final Payment. The Client shall make the final payment to the Engineer upon the completion of the Services and satisfaction of all outstanding expenses.6. ConfidentialityThe Parties agree to maintain strict confidentiality regarding all confidential information exchanged between them during the term of this Contract. Confidential information shall include, but not be limited to, project specifications, design documents, financial information, and any other proprietary or sensitive data.7. IndemnificationThe Client shall indemnify and hold harmless the Engineer against any claims, damages, losses, or expenses (including reasonable attorney's fees) arising out of or resulting from the performance of the Services, except to the extent directly caused by the negligence or willful misconduct of the Engineer.8. Governing Law and Dispute ResolutionThis Contract shall be governed by and construed in accordance with the laws of [Governing Jurisdiction]. Any disputes arising out of or in connection with this Contract shall be resolved by binding arbitrationin accordance with the rules of the [Arbitration Institution], and the decision of the arbitrator(s) shall be final and binding upon the Parties.9. Entire AgreementThis Contract constitutes the entire agreement between the Parties and supersed。

家庭景观施工合同范本英文回答：Family Landscape Construction ContractI, [Your Name], am excited to share with you this family landscape construction contract template. This contract is designed to ensure a smooth and successful landscape project for your home.First and foremost, let's talk about the project scope. This includes detls such as the size and location of the landscape area, the types of plants and materials to be used, and any specific features or structures like ponds, patios, or fences. For example, if you envision a beautiful flower garden in the front yard, we'll clearly outline the types of flowers, their arrangement, and the size of the garden bed.Next up is the timeline. We'll set a clear schedule for the project, including start and pletion dates. This helps us stay on track and ensures that you can enjoy your new landscape as soon as possible. Say, if the project is expected to take three months, we'll break it down into phases like site preparation, planting, and final touches.Then there's the cost. We'll provide a detled breakdown of all the expenses involved, including materials, labor, and any additional charges for unexpected circumstances. Let's say the cost of the plants is $500, the labor for installation is $1000, and we set aside $500 for any unforeseen issues.Quality is of utmost importance. We guarantee that all the work will be done to the highest standards, and we'll outline the warranties and guarantees for the materials and workmanship. For instance, if a plant dies within a certn period after installation, we'll replace it at no additional cost.Communication is key throughout the project. We'll establish a regular update schedule so that you're always in the loop on the progress. Maybe we'll have weekly meetings or send you photos and updates via e.In case of any disputes or issues, we'll have a clear dispute resolution process in place. This could involve mediation or arbitration to reach a fr and satisfactory oute.Finally, it's important to note that this contract is a legally binding agreement that protects both you and our pany. So, let's make sure everything is clear and agreed upon before we get started.中文回答：家庭景观施工合同我，[你的名字]，非常高兴能为您提供这份家庭景观施工合同范本。

（本）建设工程设计合同Construction Engineering Design Contract项目名称：景观设计Project Name: Landscape Design项目地点：Project Location:委托方（甲方）：Clients (Party A):承接方（乙方）：Contractor (Party B)：签订日期：年月日Date:第一章本合同依据列文件签订Chapter1. The Contract in according to following documents:1.1《中华人民共和国合同法》、《中华人民共和国建筑法》、《建设工程勘察设计市场管理规定》。

1.1《China Republic Contract Law》《China Republic Building Act》《Administrative Rule of construction project design market》1.2国家及地方有关建设工程勘察设计管理法规和规章。

1.2 National and local administrative Law and regulations of construction project design1.3建设工程批准文件。

1.3 The approval document of construction project1.4省市相关规定和本工程的实际情况。

1.4 Provincial and municipal regulations and the actual situation of the project.第二章设计咨询范围及内容Chapter2 Scope of design consultation and content 乙方设计咨询范围Scope of design consultation for Party B本次设计景观总面积约为平方米。

YOUR LOGO 景观设计合同简单范本(2021版)When concluding a contract, the parties of the contract purpose should be determined. The conclusion and performance of contracts are also human behavior.专业合同系列，下载即可用景观设计合同简单范本(2021版)导语：合同目的具有确定性。

一般情况下，在订立合同时，当事人的合同目的应该是确定的。

从严格意义而言，任何人的行为都是有目的的。

合同的订立和履行也属于人的行为，而且是比较正式的行为，所以更应该具有一定的具体目的。

因此，对于特定的合同当事人，其合同目的是确定的。

景观设计合同简单范本（一）甲方：_____乙方：_____甲方委托乙方对_____（以下简称“_____”）进行环境景观设计。

为明确甲乙双方责、权、利关系，根据《中华人民共和国合同法》和《建设工程勘察设计合同条例》，并结合本项目环境景观设计的实际情况，经双方本着平等、互利、合作的原则，友好协商，签订本合同，供双方遵照执行。

一、项目名称及地址1、项目名称：_____环境景观工程2、项目地址：_____二、设计工作内容1、甲方提供的_____用地红线范围内的环境景观设计（内容为建筑小品、道路铺装、水体、景观照明、地形造型、植物配置、给排水管网、配电系统等有关设计）；2、相关设计阶段的概、预算和有关物料样板3、施工现场监理三、设计阶段、设计深度、设计周期1、方案设计阶段（1）甲方配合内容a.向乙方提供完整、详细、准确的建筑施工总平面图、竖向标高图、市政综合管网图、单体首层平面图。

b.组织乙方现场踏勘。

c.向乙方提供项目定位标准。

（2）乙方完成内容及标准a.提供景观总体规划图（1：100的彩色、黑色各一）b.各区域大样图、剖面图、彩色草图c.方案设计说明书d.工程成本估算以上所列图纸向甲方提供三套，设计师并负责向甲方解说一次。

景观工程景观设计国际合作合同范本甲方（委托方）：_____________________地址：________________________________乙方（受托方）：_____________________地址：________________________________鉴于甲方需要进行景观工程设计，乙方具有相应的设计能力和国际合作经验，双方本着平等互利的原则，经友好协商，就甲方委托乙方进行景观工程设计项目达成如下合同条款：第一条项目概况1.1 项目名称：_____________________1.2 项目地点：_____________________1.3 设计范围：_____________________1.4 设计周期：_____________________1.5 合作方式：_____________________第二条甲方责任2.1 提供项目所需的相关资料和信息。

2.2 按合同约定支付设计费用。

2.3 协助乙方进行现场勘察和资料收集。

2.4 保证所提供资料的真实性和合法性。

第三条乙方责任3.1 按照甲方提供的要求和资料，完成景观设计工作。

3.2 保证设计质量，满足甲方和相关标准的要求。

3.3 按期提交设计成果，并负责设计成果的解释和修改。

3.4 保守甲方的商业秘密和设计资料。

第四条设计费用及支付方式4.1 设计费用总额为：_____________________4.2 支付方式：_____________________4.3 支付时间节点：_____________________4.4 其他费用：_____________________第五条知识产权5.1 乙方对设计成果拥有知识产权，未经乙方书面同意，甲方不得将设计成果用于本合同约定之外的任何目的。

5.2 甲方有权在本合同约定的范围内使用设计成果。

第六条违约责任6.1 如甲方未按约定支付设计费用，应向乙方支付违约金，违约金为未支付金额的_____%。

景观设计合同书英文回答：Landscape Design Contract。

This Landscape Design Contract (the "Contract") is entered into this [Date] by and between [Client Name] ("Client") and [Designer Name] ("Designer").1. Services。

1.1 Designer shall provide landscape design services (the "Services") to Client, as set forth in Exhibit A attached hereto and incorporated herein by reference.1.2 The Services shall include, but are not limited to:Consultation with Client to determine project goals and objectives。

Site analysis and assessment。

Conceptual design development。

Preparation of construction drawings and specifications。

Plant selection and placement。

Supervision of installation (if requested by Client)。

2. Fees and Payment。

2.1 Client shall pay Designer a total fee of [Amount]for the Services.2.2 The fee shall be payable in [Number] installments, as follows:[Percentage]% upon execution of this Contract。

景观工程英文合同This Landscae Engineering Contract (the "Contract") is made and entered into on [Date], y and etween [arty A Name], with its registered office at [Address] ("arty A"), and [arty Name], with its registered office at [Address] ("arty ").Whereas arty A intends to develo a landscae roject at [roject Location], and arty agrees to rovide the necessary goods and services for the comletion of the said roject in accordance with the terms and conditions set forth herein.Now, Therefore, the arties hereto agree as follows:1. roject DescritionThe landscae roject shall include the following works: [Detailed descrition of the landscae works including design, materials, lanting, lighting, water features, etc.]. The roject scoe maye amended uon mutual agreement in writing.2. Contract riceThe total contract rice for the landscae roject shall e [Amount in words and figures]. This rice includes all costs associated with materials, laor, transortation, and any other exenses necessary for the comletion of the works.3. ayment Termsa. An initial deosit of [ercentage]% shall e aid y arty A uon signing this Contract.. Susequent ayments shall e made in accordance with the following schedule: [Outline ayment schedule including rogress ayments, milestone ayments, etc.].c. Final ayment shall e made within [Numer] days after the comletion of the roject and satisfactory insection y arty A.4. TimelineThe landscae works shall commence on [Start Date] and shall e sustantially comleted y [Comletion Date]. Any delay in comletion eyond the secified date shall result in liquidated damages ayale y arty to arty A in the amount of [Amount er day/week] for each day/week of delay.5. Quality Standardsarty warrants that all works will e erformed to industry standards and in comliance with all alicale laws and regulations. Any defects or errors identified within the warranty eriod of [Warranty eriod] shall e romtly corrected y arty at no additional cost to arty A.6. Change OrdersAny changes to the roject scoe shall e documented in a change order form signed y oth arties. Such changes may affect the contract rice and/or comletion date.7. Liaility and Insurancea. arty shall carry all necessary insurance to rotect against liaility arising from the erformance of the works.. Neither arty shall e liale for delays caused y force majeure events such as natural disasters, acts of God, war, or other unforeseeale circumstances eyond their reasonale control.8. Disute ResolutionAny disutes arising out of or related to this Contract shall first e attemted to e resolved through negotiation etween the arties. If negotiation fails, the disute may e referred to mediation or, if necessary, litigated in the courts having jurisdiction over the matter.9. Governing LawThis Contract shall e governed y and construed in accordance with the laws of [Jurisdiction Name].10. TerminationEither arty may terminate this Contract uon written notice to the other arty in the event of a material reach of the Contract terms that remains uncorrected after [Numer] days of receit of a written notice requesting correction.11. Entire AgreementThis Contract constitutes the entire agreement etween the arties and suersedes all rior negotiations, reresentations, and agreements. Any amendments or modifications must e in writing and signed y oth arties.IN WITNESS WHEREOF, the arties have executed this Contract as of the date first aove written.[arty A Name]y: _____________________ [Authorized Signatory]Name: _______________________Title: _____________________Date: ______________________[arty Name]y: _____________________ [Authorized Signatory]Name: _______________________ Title: _____________________ Date: ______________________。

景观设计合同范文合同编号：[合同编号]甲方：[甲方（委托方）名称]乙方：[乙方（设计方）名称]第一条合同目的本合同的目的是明确乙方为甲方提供景观设计服务的相关事项。

第二条合同内容乙方根据甲方的要求进行以下服务：1.提供景观设计方案：乙方将根据甲方提供的基本资料和要求，为甲方提供详细的景观设计方案，包括但不限于设计图纸、技术说明等。

2.提供设计资料：乙方将提供包括设计文件、设计说明书等相关设计资料，供甲方使用。

3.提供施工图纸：乙方将为甲方提供详细的施工图纸和施工说明，供甲方进行后续工程施工使用。

5.提供设计变更服务：如甲方需要对景观设计方案进行变更，乙方将协助甲方进行相应设计变更，并进行相应的设计文件更新。

第三条技术标准乙方在进行景观设计服务时，应遵守国家法律法规的要求，符合行业的技术标准和规范。

乙方的设计方案应具备创新性、可行性和实用性，并符合甲方的要求。

第四条服务费用1.甲方应向乙方支付相应的景观设计服务费用。

具体的费用标准和支付方式双方另行协商确定，并在本合同附件中明确注明。

2.如甲方需要对景观设计方案进行变更，乙方将协助甲方进行相应的设计变更，但甲方需支付额外的费用。

具体的变更费用标准双方另行协商确定，并在本合同附件中明确注明。

第五条合同起止日期本合同自双方签字之日起生效，至[合同有效期结束日期]。

第六条保密条款双方应妥善保管对方提供的相关资料及知识产权，如有泄密或侵权行为，应承担相应的法律责任。

未经对方书面同意，任何一方不得将相关资料提供给第三方。

第七条违约责任1.甲方违约责任：如甲方未按照合同约定支付相应的费用，乙方有权解除合同，并要求甲方赔偿相应的损失。

2.乙方违约责任：如乙方未按照合同约定提供景观设计服务，甲方有权解除合同，并要求乙方赔偿相应的损失。

第八条其他约定1.本合同附件为合同的重要组成部分，具有同等法律效力。

2.本合同在履行过程中如发生争议，双方应友好协商解决，协商不成的，提交所在地人民法院进行诉讼解决。

工程设计合同范本英文Engineering Design Contract TemplateThis Engineering Design Contract ("Contract") is made and entered into on [date] and between [Party A Name] ("Party A") and [Party B Name] ("Party B").1. Project DescriptionParty A here retns Party B to undertake the engineering design services for the [Project Name] project (the "Project"). The scope and requirements of the design services shall be as specified in the attached Appendix [Appendix Number].2. Design Services and DeliverablesParty B shall perform the following design services:[Describe the specific design tasks and activities]The deliverables of the design services shall include, but not be limited to: [List the expected design outputs such as drawings, reports, etc.]3. Compensation and Payment TermsThe total pensation for the design services provided Party B shall be [Amount] (inclusive of taxes and fees). Party A shall make the following payments to Party B:[Describe the payment schedule and method]4. Project ScheduleThe design services shall be pleted within [estimated pletion period]. The specific milestones and deadlines shall be as follows:[List the key project milestones and their corresponding dates]5. Intellectual Property RightsAll intellectual property rights arising from the design services shall belong to [specify the owner, usually Party A or as agreed].6. ConfidentialityBoth parties undertake to keep confidential all information related to the Project and the design services.7. Liability and WarrantyParty B warrants that the design services will be performed in a professional and petent manner and in accordance with the applicable industry standards. In the event of any defect or error in the design, Party B shall be liable for rectification or pensation within a reasonable period.8. Termination and CancellationThis Contract may be terminated or cancelled under the following circumstances:[Describe the conditions for termination or cancellation]9. Dispute ResolutionAny disputes arising from or in connection with this Contract shall be resolved through friendly negotiation. If negotiation fls, the dispute shall be submitted to arbitration or litigation in accordance with the law.10. Governing Law and JurisdictionThis Contract shall be governed and construed in accordance with the laws of [applicable jurisdiction].This Contract constitutes the entire agreement between the parties and supersedes all prior negotiations, representations, and agreements.Party A: [Party A Name]Signature: [Party A Signature]Date: [Party A Date]Party B: [Party B Name]Signature: [Party B Signature]Date: [Party B Date]Appendix [Appendix Number]Please note that the above is a basic template and should be tlored to the specific circumstances and requirements of the actual project and the parties involved. Legal advice may be sought for a more prehensive and accurate contract.。

【合同协议范本】景观规划设计合同范本英文回答：Landscape Planning and Design Contract Template。

This Landscape Planning and Design Contract Template is a legally binding agreement between the Client and the Landscape Designer. It outlines the scope of work, fees, timeline, and responsibilities of both parties. By signing this contract, both parties agree to the terms and conditions set forth below.Scope of Work。

The Landscape Designer shall provide landscape planning and design services for the Client's property located at [address]. The scope of work includes:Site analysis and assessment。

Conceptual design development。

Planting plan development。

Hardscape design development。

Irrigation system design。

Lighting design。

Construction documentation。

Fees。

The Client shall pay the Landscape Designer a fee of [amount] for the services outlined in this contract. The fee shall be paid in [number] installments as follows:[Percentage]% upon signing of this contract。

绿化景观施工合同范本英文回答：Landscape Construction ContractI, [Your Name], am excited to share with you this sample of a landscape construction contract. This contract is designed to outline the terms and conditions between the contractor and the client for a successful and mutually beneficial landscaping project.The first section of the contract typically includes the names and contact detls of both the contractor and the client. For example, let's say the contractor is "Green Gardens Inc." and the client is "Mr. John Doe" residing at "123 Mn Street, Anytown, USA". This ensures clear munication channels throughout the project.The scope of work is another crucial aspect. It detls exactly what services will be provided. This could range from planting trees and shrubs, installing irrigation systems, creating walkways and patios, to laying down turf or sod. Let's imagine the project involves planting a variety of fruit trees like apple, peach, and cherry, along with a custom-designed irrigation system to ensure their proper growth.The timeline for the project is also specified. This includes the start date and the expected pletion date. Suppose the project is set to mence on May 1st and is expected to be pleted July 31st, with specific milestones along the way to monitor progress.Payment terms are an important part of the contract. It could be a bination of an initial deposit, progress payments based on pleted stages of the work, and a final payment upon satisfactory pletion. For instance, a 20% deposit might be required upfront, followed 30% after the installation of the irrigation system, another 30% after the trees and shrubs are planted, and the remning 20% upon final inspection and approval.The quality of materials and workmanship is often stipulated. The contractor guarantees to use high-quality plants, materials, and tools, and to perform the work to industry standards. If any issues arise due to subpar materials orworkmanship within a specified warranty period, the contractor is obligated to rectify the problem at no additional cost to the client.Liability and insurance coverage are also addressed. The contractor is responsible for obtning adequate insurance to cover any potential damages or injuries that may occur during the project. In case of any unforeseen circumstances, such as damage to the property or injury to workers, the insurance policy would e into play.Finally, there's a clause for dispute resolution. In the event of any disagreements or disputes, both parties agree to attempt to resolve the matter through negotiation or mediation before resorting to legal action.This is just a basic overview of a landscape construction contract. It's essential to have a detled and customized contract based on the specific requirements and circumstances of each project.中文回答：绿化景观施工合同我呀，[你的名字]，特别高兴能给您讲讲这个绿化景观施工合同的范例。

景观设计收费标准及合同范本English Answer：Landscape Design Pricing Structures.Landscape design fees vary widely depending on the size, complexity, and location of the project. The most common pricing structures are:Hourly rate: This is the most straightforward pricing structure, where the designer charges an hourly rate for their time. Hourly rates typically range from $50 to $200 per hour.Flat fee: This is a fixed price for the entire project, regardless of the number of hours required. Flat fees are typically quoted for smaller, less complex projects.Percentage of construction cost: This pricingstructure is based on a percentage of the total cost of thelandscape construction. The percentage typically ranges from 10% to 20%.Contract Template.A landscape design contract should clearly outline the following:Scope of work: This should include a detailed description of the services to be provided by the designer, such as site analysis, design development, and construction documentation.Fees: The contract should specify the pricingstructure and payment terms.Timeline: The contract should include a start date and a completion date for the project.Responsibilities: The contract should clearly define the responsibilities of both the designer and the client.Termination: The contract should include a termination clause that outlines the conditions under which either party can terminate the agreement.Chinese Answer：景观设计收费标准。

建设工程设计合同Engineering Service Contract（专业建设工程设计合同）(Professional Engineering Service Contract For Construction Project)工程名称：Name of the project:工程地点：Location of the project:合同编号：（由设计人编填）Contract No.:(Filled in by the Designer)设计证书等级：Level of the design certificate:发包人：Employer:设计人：Designer:签定日期：Date of contract:江苏省工商行政管理局发包人:Employer: (Party A)设计人:Designer: (Party B)发包人委托设计人承担工程设计,工程地点为,经双方协商一致,签订本合同,共同执行。

The Employer entrust the Designer to undertake the engineering design of *** and the location for the project is within the plant of .Afterfriendly consultation, the Parties hereby sign this Contract as follows：第一条本合同签订依据。

Article 1 Basis for the conclusion of this Contract1.1《中华人民共和国合同法》、《中华人民共和国建筑法》、《建设工程勘察设计市场管理规定》。

1.1 The Contract Law of the People’s Republic of China; The ConstructionLaw of the People’s Republic of China; Regulations on the Administrationof the Market for Survey and Design of Engineering Construction.1.2 国家及地方有关建设工程勘察设计管理法规和规章。

景观施工合同范本英文回答：Landscape Construction Contract TemplateI'm really happy to share this landscape construction contract template with you. When it es to a landscape construction contract, it's super important to have all the detls sorted out to avoid any headaches down the road.Let's start with the basics. The contract should clearly state the names and contact information of both the contractor (that's me) and the client. For example, if my name is John Doe and I'm running a landscape business called "Green Oasis Landscaping," and the client is named Jane Smith, we'd have that right up front.The scope of work is another crucial part. This spells out exactly what I'm going to do for the client. Say it includes designing and installing a new flower bed, laying down a patio, and planting some trees. Each task should be described in detl, like the size and type of the flower bed, the materials for the patio, and the species and number of trees.The timeline is a biggie too. We need to set clear deadlines for each stage of the project. Maybe I promise to have the design pleted within two weeks, the flower bed installed in another week, and the whole project wrapped up in a month. And if there are any delays, we need to figure out who's responsible and what the consequences are.Payment terms are a must. We'd lay out how much the client is going to pay me, when the payments are due, and what happens if they're late. For instance, the total cost might be $10,000, with a 30% deposit upfront, another 30% after the design is approved, and the remning 40% upon pletion.Then there's the warranty. I'd offer a guarantee on my work for a certn period, say a year. If anything goes wrong within that time, I'll e back and fix it at no extra cost to the client.Insurance is also something to cover. I need to make sure I have the right insurance to protect both me and the client in case of any accidents or damages during the project.And don't forget about dispute resolution. In case there's a disagreement between me and the client, we'd have a process in place to sort it out, like arbitration or mediation.So, that's a rough outline of a landscape construction contract. Remember, every project is different, so you might need to tweak things here and there to fit your specific situation.中文回答：景观施工合同范本我很高兴能跟您分享这份景观施工合同范本。

**花园一期景观工程设计合同发包人：1、设计人: **景观设计（香港）有限公司2、发包人和设计人就——————一期景观环境设计工程, 为明确双方权利、义务和责任, 保证工程设计质量, 按期交付设计图纸, 经双方充分协商, 同意签订本合同, 并共同遵守。

1.1本合同签订依据:1.2《中华人民共和国合同法》、《中华人民共和国建筑法》、《建设工程勘察设计市场管理规定》。

1.3国家及地方有关建设工程勘察、设计管理法规和规章及现行设计规范。

1.4建设工程批准文件。

合同设计项目的内容:名称、规模及设计费等:2.1 项目概况：本项目位于武汉市————处。

项目规划用地为816亩, 其中工业用地面积48亩, 净规划建设用地面积约为768亩, 容积率1.8, 计容积率总建筑面积约80万㎡。

计划分四期实施（一期暂按40%用地面积考虑）。

工程总拟建占地面积约为11万平方米, 可建净用地面积约为9万平方米, 地上建筑面积合计约163,000 m², 地下建筑面积约13,000 m², 半地下停车场的建筑面积约为4200 m²。

景观设计面积约7万平米（包括架空层内景观设计)。

2.2 设计内容: 为概念、方案、扩初、施工图设计(含给排水、电力、隐蔽工程的结构设计及各单项土建工程详图如景亭、广场、小区含组团围墙、小区及组团出入口门楼（岗）、栈桥、水池、喷泉等)、现场施工指导。

3、 2.3 设计费用：本次设计费用为包干价万元整（人民币大写：）,此费用包括设计人设计人员免费到现场共40人*次, 主要是参与设计协调、答疑、交底、修正、指导。

今后因政府部门审批原因而引起景观设计修改不再调整设计费。

4、 2.4 本工程园林设计分两期, 一期为9栋9层住宅、2栋11层住宅、一栋半地下室、营销中心及东南角酒店式公寓单体。

其余为二期。

5、设计进度及要求:5.1总体概念方案阶段: 收到发包人设计委托书或设计合同之日起15工作日内完成。

EPC绿化设计施工合同模板英文版EPC Greening Design and Construction Contract TemplateThis document serves as a template for an Engineering, Procurement, and Construction (EPC) contract specifically tailored for green design and construction projects. It outlines the terms and conditions that both parties must adhere to throughout the project lifecycle.1. Scope of Work: The contractor shall provide all necessary design, procurement, and construction services for the greenification of the designated area as outlined in the project specifications.2. Timeline: Both parties agree to adhere to the project timeline as set forth in the project schedule. Any delays must be communicated promptly and addressed accordingly.3. Payment Terms: The client agrees to pay the contractor according to the payment schedule outlined in the contract. Payment milestones will be tied to project deliverables and completion stages.4. Quality Control: The contractor is responsible for ensuring that all materials and workmanship meet the highest standards of quality and comply with green design principles.5. Change Orders: Any changes to the scope of work must be documented in writing and approved by both parties before implementation. Additional costs resulting from changes will be negotiated separately.6. Insurance and Liability: The contractor shall maintain appropriate insurance coverage for the duration of the project and shall be liable for any damages or losses resulting from their work.7. Termination: Either party may terminate the contract in writing if the other party fails to fulfill their obligations. Termination procedures and any associated penalties will be outlined in the contract.8. Dispute Resolution: In the event of any disputes arising from the contract, both parties agree to first attempt to resolve the issue through mediation. If mediation is unsuccessful, arbitration or legal action may be pursued.9. Confidentiality: Both parties agree to keep all project-related information confidential and not disclose any proprietary or sensitive information to third parties.10. Governing Law: This contract shall be governed by the laws of the jurisdiction in which the project is located.By signing below, both parties acknowledge their acceptance of the terms and conditions outlined in this EPC Greening Design and Construction Contract Template._______________________________________________________________Client Signature Contractor SignatureDate: _________________ Date: _________________。