装饰施工合同中英文对照

工程装修英文合同范本CONTRACT FOR ENGINEERING DECORATIONThis Contract is made and entered into as of [date] and between [Party A's name] (hereinafter referred to as "Party A") and [Party B's name] (hereinafter referred to as "Party B").WHEREAS, Party A desires to have certn decoration works carried out on the project, and Party B has the necessary expertise and capabilities to undertake such works.NOW, THEREFORE, in consideration of the mutual covenants and agreements hereinafter set forth, the parties agree as follows:1. Scope of Work: Party B shall perform the decoration works in accordance with the plans, specifications, and requirements provided Party A. The specific scope of work shall be detled in the attached Appendix.2. Time for Completion: Party B agrees to plete the decoration works within [specified time period] from the mencement date.3. Payment: Party A shall pay Party B the contract price of [amount] in the following installments: [detl the payment schedule].4. Quality Assurance: Party B guarantees that the decoration works will be of high quality and conform to industry standards. In the event of any defects or deficiencies, Party B shall be obligated to make prompt reprs or corrections.5. Change Orders: Any changes to the scope of work or specifications shall be mutually agreed upon in writing and may result in adjustments to the contract price and time for pletion.6. Warranties: Party B provides a [length of warranty] warranty for the decoration works from the date of pletion.7. Liabilities and Indemnification: In the event of any loss, damage, or liability arising from the performance of the decoration works, the parties shall be liable in accordance with the terms and conditions herein.8. Termination: Either party may terminate this contract in the event of a material breach the other party, subject to notice and an opportunity to cure.9. Dispute Resolution: In the event of any disputes or differences arising out of or in connection with this contract, the parties shall attempt to resolve them through amicable negotiations. If unsuccessful, the matter shall be submitted to arbitration in accordance with the rules of [arbitration body].10. Miscellaneous: This contract contns the entire agreement between the parties and supersedes all prior negotiations and understandings. Any amendments or modifications shall be in writing and signed both parties.IN WITNESS WHEREOF, the parties have hereunto set their hands and seals on the day and year first above written.Party A: [signature and detls]Party B: [signature and detls]Please note that this is just a sample and may need to be customized and adjusted according to the specific circumstances and requirements of your project. It is advisable to consult with a legal professional to ensure the contract is prehensive and enforceable.。

装修装饰工程施工合同(中英文）CONTRACT OF DECORATION ENGINEERING签署日期Date of工程名称：Project Name:工程地址：Project Place:发包方 (甲方)： Owner (Hereinafter referred to as party A)承包方 (乙方)： Contractor: (hereinafter called party B)鉴于甲方拟对办公楼进行装修装饰，通过招投标程序，将该工程授予乙方施工并完成；鉴于乙方具备装修装饰施工的资质，并愿意接受招投标规定的条件，同意承担该工程的施工并完成；鉴于双方同意遵照《中华人民共和国合同法》、《建筑装饰装修管理规定》、《住宅室内装饰装修管理办法》及有关法律、法规规定履行本合同；基于本合同之合意、声明、约定及其它约因，双方当事人兹就下列各事项达成协议：WHEREAS party A intends to make decoration of office building, through bidding procedure, award this project hereby to party B for construction and completion thereof.WHEREAS party B is with the qualification of decoration engineering, intends to accept bidding conditions and consent to undertake the project construction and complete.WHEREAS parties hereto agree to execute this contract in accordance with LAW OF CONTRACT, REGULATIONS OF CONSTRUCTION DECORATION MANAGEMENT, ADMINISTRATION RULES FOR INDOOR HOME DECORATION and concerned laws and regulations.NOW THEREFORE in consideration of the mutual promises, assertions and covenants herein and other good and valuable considerations, the receipts of which is acknowledged hereby, the parties hereby agree as follows:第一条工程概况 Work Overview1、工程名称： Project Name2、工程地址： Project Place:3、承包方式：总承包（包工包料，包质量，包安全，包工期）Contracting Means: General contracting, including contracting of materials and labor, liabilities of quality, work’s safety and work’s schedule.4、承包内容：包括所有的拆除及改造工程，以附件《工程报价单》为准。

建筑施工合同中英文对照7篇篇1建筑施工合同Contract of Construction一、合同当事人The Parties to the Contract1. 发包人（甲方）：_________，公司注册地址：_________，法定代表人：_________，联系电话：_________，传真号码：_________，邮政编码：_________。

1. The Employer (Party A): _________ , registered address of the company: __________, legal representative: __________, contact number: __________, fax number: __________, post code: __________.2. 承包人（乙方）：_________，公司注册地址：_________，法定代表人：_________，联系电话：_________，传真号码：_________，邮政编码：_________。

2. The Contractor (Party B): __________, registered address of the company: __________, legal representative: __________, contact number: __________, fax number: __________, post code: __________.二、合同标的The Subject of the Contract本合同标的为：_________（具体项目名称）。

The subject of this contract is: _________ (specific project name).三、合同工期Contract Time Limit1. 开工日期：本合同工程开工日期为_________年_________月_________日。

GF-96-0206建筑装饰工程施工合同The building decorates engineering a construction contract(乙种本) (B grows originally)发包方(甲方):Send report a square(the first party):承包方(乙方):Contract for a square(the second party):依照《中华人民共和国合同法》和《建筑安装工程承包合同条例》的规定,结合本工程具体情形,两边达到如下协议。

According to 《the People's Republic of China contract method 》and 《building gearing the en gineering contract for contract regulation 》of provision, combine a this engineering concrete ci rcumstance, both parties are reached as follows to negotiate.第1条工程概况The 1st engineering general situation1．1工程名称:engineering name:1．2工程地址:engineering locations:1．3承包范围:contract for scope:1．4承包方式:contract for a way:1．5工期:本工程自年月日动工,于年月日完工。

1．6工程质量:engineering qualities:1．7合同价款(人民币大写):contract payment(renminbi capital letter)s:第2条甲方工作The 2nd first party works2．1动工前天,向乙方提供经确认的施工图纸或作法说明份,并向乙方进行现场交底。

建筑装饰工程施工合同范本中英文一、合同概述建筑装饰工程施工合同是业主（发包方）与施工方（承包方）之间就建筑装饰工程项目的实施所达成的具有法律效力的协议。

这份合同明确了双方的权利和义务，包括工程的范围、质量标准、工期、价款及支付方式等重要条款，旨在保障工程的顺利进行和双方的合法权益。

二、合同主体部分（一）合同双方的基本信息1、发包方（业主）：名称：＿____地址：＿____联系电话：＿____法定代表人：＿____2、承包方（施工方）：名称：＿____地址：＿____联系电话：＿____法定代表人：＿____（二）工程概况1、工程名称：＿____2、工程地点：＿____3、工程内容：包括但不限于室内装修、外立面改造、电气安装、给排水工程等具体的装饰施工内容。

（三）工程期限1、开工日期：＿____2、竣工日期：＿____3、总工期：＿____天（四）工程质量和验收标准1、工程质量标准：应符合国家及地方相关的建筑装饰工程质量标准和规范，如《建筑装饰装修工程质量验收规范》等。

2、验收程序和方式：分为阶段性验收和竣工验收。

阶段性验收在每个施工节点完成后进行，竣工验收在工程全部完成后进行。

验收应依据双方事先约定的标准和程序进行，由发包方组织相关人员进行验收。

三、工程价款及支付方式（一）工程价款1、本工程总价款为：＿____元（人民币/美元等）。

2、价款构成：包括材料费用、人工费用、管理费、利润、税金等各项费用。

（二）支付方式1、预付款：合同签订后，发包方应向承包方支付工程总价款的_____%作为预付款，即：＿____元。

2、进度款：根据工程进度，发包方应按约定的比例支付进度款。

例如，在工程完成_____%时，支付工程总价款的_____%；在工程完成_____%时，支付工程总价款的_____%等。

3、竣工结算款：工程竣工验收合格后，承包方应提交竣工结算报告，发包方在审核确认后支付至工程总价款的_____%，剩余_____%作为质量保证金。

第1篇Contract No.: [Contract Number]Date: [Contract Date]Parties Involved:1. Contractor:- Name: [Contractor's Name]- Address: [Contractor's Address]- Contact Person: [Contractor's Contact Person]- Contact Information: [Contractor's Contact Information]2. Client:- Name: [Client's Name]- Address: [Client's Address]- Contact Person: [Client's Contact Person]- Contact Information: [Client's Contact Information]Scope of Work:1. Project Description: [Detailed description of the construction project, including type of project, location, and main objectives.]2. Work to be Performed: [List of all the specific tasks and activities to be carried out by the Contractor, including design, construction, and any other related services.]3. Deliverables: [Detailed list of all deliverables, including but not limited to drawings, specifications, progress reports, and final certificates of completion.]Contract Price and Payment Terms:1. Contract Price: [Total contract price including all costs, fees, and expenses.]2. Payment Schedule:- Progress Payments: [Details of progress payments, including payment milestones, percentage of work completed, and payment schedule.]- Final Payment: [Conditions and terms for the final payment, including completion and final inspection requirements.]3. Retention: [Percentage of the contract price to be retained until the project is completed and all conditions are met.]Duration of the Contract:1. Start Date: [Date when the work is to begin.]2. Completion Date: [Estimated completion date based on the project scope and schedule.]3. Extension of Time: [Conditions under which the completion date may be extended and the process for requesting an extension.]Quality Standards:1. Quality Requirements: [Specific quality standards to be adhered to during the construction process, including materials, workmanship, and compliance with relevant codes and regulations.]2. Inspection and Testing: [Provisions for regular inspections and testing to ensure compliance with quality standards.]Warranties and Liabilities:1. Warranties: [Details of warranties provided by the Contractor, including duration and scope of warranty coverage.]2. Liabilities: [Responsibilities and liabilities of the Contractor in the event of any defects, damages, or claims arising from the work performed under the contract.]Force Majeure:1. Definition: [Definition of force majeure events, including acts of God, war, strikes, labor disputes, and any other events beyond the reasonable control of the Contractor.]2. Effect: [Provisions regarding the suspension of the contract and the obligations of the parties in the event of a force majeure event.]Dispute Resolution:1. Arbitration: [Provisions for resolving disputes, including the procedure for arbitration and the appointment of an arbitrator.]2. Legal Actions: [Conditions under which legal actions may be taken and the jurisdiction of any disputes.]General Provisions:1. Governing Law: [The laws of the jurisdiction that will govern the interpretation and enforcement of the contract.]2. Amendments: [Provisions regarding the process for making amendments to the contract.]3. Termination: [Conditions under which the contract may be terminated and the consequences of termination.]Acknowledgment:The parties hereto acknowledge that they have read, understand, and agree to be bound by the terms and conditions of this Construction Engineering Contract.---Contract No.: [Contract Number]Date: [Contract Date]Contractor:[Signature of Contractor] ___________________________[Name of Contractor] ___________________________Client:[Signature of Client] ___________________________[Name of Client] ___________________________---Note: This is a general template for a construction engineering contract. Specific contracts may require additional details or clauses based onthe nature of the project and the requirements of the parties involved.It is recommended that legal advice be sought when drafting or entering into a construction contract.第2篇Contract No. __________Contract Date: __________Contractor: __________Client: __________1. IntroductionThis Construction Engineering Contract (hereinafter referred to as "the Contract") is entered into between __________ (hereinafter referred toas "the Contractor") and __________ (hereinafter referred to as "the Client") on the basis of mutual consultation, agreement, and mutual benefit. The Contractor agrees to construct and complete theconstruction project as specified in the Contract, and the Client agrees to pay the agreed contract price for the completed construction project. The Contract is binding on both parties and shall be strictly observed.2. Project Description2.1 Project Name: __________2.2 Project Location: __________2.3 Project Scope: The construction project includes the following scopes:a. Civil engineering works: __________b. Electrical engineering works: __________c. Mechanical engineering works: __________d. Other relevant works: __________3. Contract Price3.1 The total contract price for the construction project is __________ Yuan, which is subject to the following terms:a. The Contractor shall provide detailed project estimates and invoices for the Client's approval.b. The Client shall make payment in accordance with the agreed payment schedule.c. Any additional costs due to changes in the project scope or unforeseen circumstances shall be agreed upon by both parties in writing.4. Performance and Quality4.1 The Contractor shall ensure that the construction project is completed within the agreed time frame and meets the quality standards specified in the Contract.4.2 The Contractor shall adhere to the relevant national standards,local regulations, and industry practices during the construction process.4.3 The Client shall have the right to inspect and accept the construction project at any time during the construction process.5. Payment Schedule5.1 The payment schedule is as follows:a. Upon the signing of the Contract, the Client shall pay the Contractor a deposit of __________ Yuan.b. Upon the completion of each phase of the project, the Contractor shall submit an invoice to the Client for payment.c. The Client shall pay the invoice within __________ days upon receipt.6. Insurance6.1 The Contractor shall obtain and maintain all necessary insurance policies to cover the risks associated with the construction project, including but not limited to:a. Public liability insuranceb. Workers' compensation insurancec. Property insurance7. Termination of the Contract7.1 Either party may terminate the Contract in writing if the other party fails to comply with the terms and conditions of the Contract.7.2 Upon termination of the Contract, the Contractor shall immediately cease all construction activities and the Client shall pay the Contractor for the work completed up to the date of termination.8. Dispute Resolution8.1 Any disputes arising from the execution of the Contract shall be settled through friendly negotiations between the parties.8.2 If the parties fail to reach an agreement through negotiations, the dispute shall be submitted to the relevant arbitration commission for resolution.9. Governing LawThis Contract shall be governed by the laws of __________.10. Final Provisions10.1 This Contract constitutes the entire agreement between the parties and supersedes all prior agreements and understandings, whether written or oral.10.2 Any amendment or modification of this Contract shall be effective only if it is in writing and signed by both parties.Contractor Signature: ___________________________Client Signature: ___________________________Date: ___________________________---Construction Engineering ContractContract No. __________Contract Date: __________Contractor: __________Client: __________1. Introduction本建筑工程合同（以下简称“本合同”）由__________（以下简称“承包商”）与__________（以下简称“业主”）在相互协商、一致同意和互惠互利的基础上签订。

工程施工合同中英对照【合同名称】Contract Name: Construction roject Agreement甲方（业主）arty A (Owner): _________________乙方（承包商）arty (Contractor): _________________鉴于双方基于平等、自愿的原则，经过友好协商，就________项目的建设达成如下协议：Whereas oth arties, on the asis of equality and voluntariness, have reached the following agreement through friendly negotiation concerning the construction of the ________ roject.一、项目概述 roject Overview:1. 工程名称 Name of the roject: _____________2. 工程地点 Location of the roject: _____________3. 工程规模 Scale of the roject: _____________4. 工程内容 Content of the roject: _____________5. 工期要求 Duration Requirements: _____________二、合同金额 Contract Amount:1. 合同总价 Total Contract rice: _____________2. 付款方式 ayment Method: _____________3. 付款条件 ayment Conditions: _____________三、工程进度 roject Schedule:1. 开工日期 Start Date: _____________2. 竣工日期 Comletion Date: _____________3. 进度安排 Schedule Arrangement: _____________四、质量要求 Quality Requirements:1. 标准规范 Standard Secifications: _____________2. 验收标准 Accetance Criteria: _____________3. 质量保证措施 Quality Assurance Measures: _____________五、变更与索赔 Changes and Claims:1. 变更程序 Change rocedures: _____________2. 索赔条件 Claim Conditions: _____________3. 处理流程 Handling rocess: _____________六、违约责任 Liaility for reach:1. 违约定义 Definition of reach: _____________2. 违约处罚 enalties for reach: _____________3. 解决方式 Resolution Methods: _____________七、争议解决 Disute Resolution:1. 协商解决 Negotiated Settlement: _____________2. 仲裁条款 Aritration Clauses: _____________3. 适用法律 Alicale Law: _____________八、其他事宜 Miscellaneous:1. 附加条款 Additional rovisions: _____________2. 通知方式 Notice Method: _____________3. 合同生效条件 Effective Conditions of the Contract: _____________九、附件 Annexes:1. 设计图纸 Design Drawings: _____________2. 技术规范 Technical Secifications: _____________3. 相关文件 Relevant Documents: _____________本合同一式两份，甲乙双方各执一份，自双方签字盖章之日起生效。

第1篇This contract is made and entered into on [Date] between [Contractor's Name], hereinafter referred to as "Contractor", and [Client's Name], hereinafter referred to as "Client", both parties hereinaftercollectively referred to as "the Parties".1. Project ScopeThe Contractor shall undertake the decoration project of [Project Name], located at [Project Address]. The scope of work includes, but is not limited to, the following:1.1 Interior decoration design, including wall painting, flooring, ceiling, and decoration materials selection.1.2 Electrical installation, including lighting, power supply, and communication lines.1.3 Water supply and drainage installation, including pipes, valves, and faucets.1.4 Installation of doors and windows, including hardware and glass.1.5 Installation of sanitary ware, including toilets, bathtubs, and sinks.1.6 Other auxiliary works as agreed upon by both parties.2. Project Schedule2.1 The project shall be completed within [Completion Period] from the date of contract signing.2.2 The Contractor shall submit a detailed construction schedule to the Client within [Time Limit] after the contract signing, specifying the start and completion dates of each work item.2.3 The Contractor shall strictly follow the construction schedule and report any delays to the Client in advance.3. Payment Terms3.1 The total contract amount is [Contract Amount], which shall be paid in installments as follows:3.1.1 30% upon the signing of the contract.3.1.2 30% upon the completion of the design and procurement of decoration materials.3.1.3 30% upon the completion of the construction and acceptance of the project.3.1.4 10% as retention money, to be released upon the completion of the project and the Client's satisfaction with the quality of work.3.2 The payment method shall be made by bank transfer or cash, as agreed upon by both parties.4. Quality Requirements4.1 The Contractor shall ensure the quality of work in accordance with relevant national standards and regulations.4.2 The quality of decoration materials shall meet the requirements of the contract and industry standards.4.3 The Contractor shall be responsible for any defects or damages caused by the quality of work or materials.5. Warranty5.1 The Contractor shall provide a warranty period of [Warranty Period] for the project, during which any defects or damages caused by the quality of work or materials shall be repaired or replaced free of charge.5.2 The warranty period shall start from the date of project completion and acceptance.6. Termination and Liability6.1 Either party may terminate this contract upon written notice if the other party fails to fulfill its obligations under this contract.6.2 In case of termination, the Parties shall negotiate and reach an agreement on the handling of the terminated project.6.3 The Contractor shall be liable for any losses or damages incurred by the Client due to the Contractor's breach of contract.7. Dispute Resolution7.1 Any disputes arising from the execution of this contract shall be settled through friendly negotiations between the Parties.7.2 If the Parties fail to reach an agreement through negotiations, the dispute shall be submitted to the people's court of the place where the project is located for trial.8. General Provisions8.1 This contract is governed by the laws of [Country/Region].8.2 Any amendment or supplement to this contract shall be effective only if it is made in writing and signed by both Parties.8.3 This contract constitutes the entire agreement between the Parties and supersedes all prior agreements, negotiations, and understandings, both written and oral.In witness whereof, the Parties have executed this contract as of the date first above written.Contractor: ___________________________Name: ________________________________Date: ________________________________Client: _______________________________Name: ________________________________Date: ________________________________第2篇This Contract is hereby entered into as of [Date of Execution], by and between the following parties:Contractor:[Contractor's Full Name][Contractor's Address][Contractor's Contact Information]Client:[Client's Full Name][Client's Address][Client's Contact Information]WHEREAS, the Client desires to have the services of the Contractor for the decoration and construction of the property located at [Property Address]; andWHEREAS, the Contractor is willing to provide such services upon the terms and conditions set forth herein;NOW, THEREFORE, in consideration of the mutual covenants and agreements hereinafter set forth, the parties hereto agree as follows:1. Scope of Work:The Contractor shall perform all necessary work to complete the decoration and construction of the property as outlined in the attached Scope of Work Document. The Scope of Work includes, but is not limited to, the following:- Renovation of existing structures and spaces- Installation of new fixtures, fittings, and appliances- Painting and wallpapering- Floor covering installation- Electrical and plumbing work- Installation of doors and windows- Landscaping and outdoor improvements2. Project Schedule:The project shall commence on [Start Date] and is expected to be completed by [Completion Date]. The Contractor shall provide the Client with a detailed project schedule outlining the timeline for each phase of the work.3. Payment Terms:- The total cost of the project shall be [Total Cost], which shall be paid in [Number] installments.- The first installment of [Amount] shall be paid upon execution of this Contract.- Subsequent installments shall be paid at the following intervals:- [Amount] upon the completion of [Phase 1]- [Amount] upon the completion of [Phase 2]- [Amount] upon the completion of [Phase 3]- [Amount] upon the final completion of the project- Any changes to the payment schedule shall require written agreement from both parties.4. Change Orders:Any changes to the Scope of Work or project schedule shall be documented in a Change Order, which shall be executed by both parties before the changes are implemented.5. Quality of Work:The Contractor shall perform all work in a professional and workmanlike manner, in accordance with the applicable codes and standards.6. Insurance:The Contractor shall maintain, during the course of this Contract, all necessary insurance policies, including general liability insurance, workers' compensation insurance, and property damage insurance. The Contractor shall provide the Client with proof of insurance upon request.7. Warranties:The Contractor warrants that all materials and workmanship used in the project shall be free from defects for a period of [Warranty Period]from the date of final completion.8. Termination:This Contract may be terminated by either party upon the occurrence of any of the following events:- Failure of the Contractor to perform the work in accordance with the terms of this Contract- Failure of the Client to make payments as agreed- Breach of any warranty or representation made by either party9. Governing Law:This Contract shall be governed by and construed in accordance with the laws of [Jurisdiction].10. Entire Agreement:This Contract constitutes the entire agreement between the parties with respect to the subject matter hereof and supersedes all prior agreements, understandings, negotiations, and discussions, whether oral or written.IN WITNESS WHEREOF, the parties hereto have executed this Contract as of the date first above written.Contractor's Signature:_________________________Name:_________________________Date:_________________________Client's Signature:_________________________Name:_________________________Date:_________________________第3篇This Contract is made and entered into on [Date] between the following parties:Contractor:[Contractor's Full Name][Contractor's Address][Contact Information: Phone Number, Email]Client:[Client's Full Name][Client's Address][Contact Information: Phone Number, Email]WHEREAS, the Client desires to have a decoration project completed at [Project Location], and the Contractor is willing to undertake the same for the Client on the terms and conditions set forth herein.NOW, THEREFORE, in consideration of the mutual covenants and agreements contained herein, the parties agree as follows:1. Scope of Work:The Contractor shall perform all work necessary to complete the decoration project at [Project Location] in accordance with the plans,specifications, and schedule provided by the Client. The work shall include, but not be limited to, the following:- Removal of existing fixtures and fittings.- Installation of new electrical, plumbing, and HVAC systems.- Application of paint, wallpaper, and other finishes.- Installation of flooring, cabinetry, and hardware.- Completion of all other decorative elements as specified in the plans and specifications.2. Project Schedule:The Contractor shall complete the work within [Number of Days/Months] from the commencement date, which is [Commencement Date]. Any delays shall be communicated to the Client in writing, and a revised schedule shall be agreed upon by both parties.3. Payment Terms:The Client shall pay the Contractor as follows:- A non-refundable deposit of [Amount] upon the signing of this Contract.- [Percentage]% of the total contract price upon the completion of [Percentage]% of the work.- The remaining [Percentage]% of the total contract price upon the final completion and approval of the work by the Client.- All payments shall be made within [Number of Days] from the date of the invoice.4. Change Orders:Any changes to the scope of work, schedule, or payment terms shall be made by written Change Order signed by both parties. Such Change Orders shall become part of this Contract and shall be subject to the same terms and conditions.5. Materials and Quality:The Contractor shall use only quality materials and comply with all applicable building codes and regulations. The Contractor shall provide the Client with samples of materials and finishes prior to their installation, and the Client shall have the right to approve or reject any materials or finishes.6. Warranties:The Contractor warrants that all work performed under this Contract shall be free from defects in workmanship and materials for a period of [Number of Years] from the date of final completion. The Contractor shall rectify any defects notified by the Client within a reasonable time.7. Insurance:The Contractor shall maintain comprehensive general liability insurance and workers' compensation insurance with limits satisfactory to the Client. The Contractor shall provide proof of insurance upon request.8. Dispute Resolution:In the event of any dispute arising out of this Contract, the parties shall first attempt to resolve the matter amicably. If the dispute cannot be resolved within [Number of Days], it shall be submitted to arbitration by a mutually agreed-upon arbitrator.9. Governing Law:This Contract shall be governed by and construed in accordance with the laws of [Jurisdiction].10. Entire Agreement:This Contract constitutes the entire agreement between the parties and supersedes all prior agreements, negotiations, and understandings, whether written or oral.IN WITNESS WHEREOF, the parties have executed this Contract as of the date first above written.Contractor's Signature:_________________________Name:_________________________Date:_________________________Client's Signature:_________________________Name:_________________________Date:_________________________NOTICE:Please read this Contract carefully before signing. If there are any terms or conditions that you do not understand or agree with, please consult with a legal professional before executing this Contract.。

C o n t r a c t f o rD e c o r a t i o n P r o j e c tParty A (full name):Party B (full name):This Contract is concluded on the basis of the project details by and between the foresaid Party A and Party B in accordance with Contract Law of People’s Republic of China and Construction Engineering Contract Regulations.1. Overview1.1 Project name:1.2 Project site:1.3 Project content:1.4 Means of contract:1.5Construction Period is from date of commence of , to completion date of .1.6 Quality standard:1.7 Contract price:2. Party A’s Responsibilities2.1 Party A shall provide copy of confirmed construction drawings or instructions to Party B Days prior to the date of commence, clear up all or parts of the buildings, and remove barriers. Party A will take protective measures for the remaining furniture and furnishings. Party A also needs to provide water, electricity, gas and telecommunications, and indicate matters needing attention to Party B. Party A will be responsible for going through all the applications andapproval procedures related to the project.2.2Party A assigns to be the representative. He will be responsible for the supervision and control over the project, and handle the acceptance, alteration, registration formalities.2.3Party A entrusts with the construction supervision of this project. The supervision company appoints to be the general supervision engineer, clarifies his responsibilities in the supervision contract, and submits copy of the contract to Party B.2.4 Party A shall be responsible for protecting the surrounding buildings, equipments, pipelines, trees and landscaping from being damaged, and bear corresponding costs.2.5 If it is really necessary to change the original building structure or pipelines, Party A shall be responsible for going through the corresponding approval procedures.2.6Party A will coordinate with relevant departments to do on-site security, fire protection, waste disposal, etc., and bear the corresponding costs.3. Party B’s Responsibilities3.1Party B must be available to attend meetings organized by Party A and prepare construction plan and schedule.3.2 Party B assigns as the site resident representative. He will be responsible for construction organization and completion of the project with good quality.3.3 Party B shall strictly implement the construction specifications, safety operation procedures, fire safety regulations, and environmental protection regulations. It must?strictly?execute?construction?abiding?by constructiondrawings or practice instructions, and complete the quality inspection record. Party B must participate in the final completion acceptance, and prepare the project settlement.3.4Party B must abide by the provisions on the management of the construction sites by the national or local government and related departments, protect the surrounding buildings, equipments, pipelines, trees and landscaping from being damaged. Party B also need to do a good job in such things as the construction site security and garbage disposal, and deal well with the issue of disturbing residents brought about by construction.3.5Without Party A's consent or approval of relevant departments, Party B shall not make any unauthorized changes to original building structure or pipelines.3.6Party B shall be responsible for protecting all the facilities and finished projects before the project is handed over to Party A.4. Construction Period4.1When Party A needs to complete the project ahead of the time limit, it should obtain Party B's agreement and pay the cost for the measures that Party B takes to crash the schedule.4.2 If the project progress is influenced by the delay of Party A's delivery date, the practically impacted cycle extends accordingly.4.3If the project can not be started on time or shutdown halfway for no reason because of Party B's responsibility, the practically impacted cycle can not extend accordingly.4.4 The project duration shall be prolonged when the downtime is over eight hours (accumulated in one week) caused by the power failure, water failure, gas stop and force majeure factors because of design changes or reasons not relatedto Party B.5. Quality Standard and Acceptance Inspection5.1This project takes construction drawings, instructions, design changes and national construction and acceptance specifications such as Construction and Acceptance Standards of Decoration Engineering (JGJ73-91), Unified Quality Inspection and Assessment of Architectural Installation Work (GBJ300-88)as quality assessment and acceptance standards.5.2 Quality of the project should meet the acceptance criterion of national quality assessment. If all or parts of the project reach to the excellent standard, Party A will pay to Party B increased costs.5.3 Party A and Party B shall promptly handle the concealed work inspection procedures of pre-acceptance in the middle of the project. If Party A do not organize covert acceptance in time, Party B can make self-inspection and Party A shall admit the result. If Party A requires the re-inspection, Party B shall be in accordance with the requirements for the re-inspection. If the re-inspection result is acceptable, Party A shall bear the re-inspection fee and the project duration can be extended accordingly; if re-inspection result is not acceptable, the re-inspection and reworking costs shall be borne by Party B, and the project duration shall also be extended accordingly.5.4 If materials provided by Party A for the construction do not meet the necessary requirements, Party A shall bear responsibility for any resulting delays in the completion of the project.5.5 If the quality of Party B's work results in any accidents, liability for such accidents shall be borne by Party B.5.6 When the Project is ready for final acceptance, Party B shall submit to Party A the full as-built documentations and completion acceptance report. PartyA shall organize the acceptance within 5 day after receiving all the documents. When Party A can not conduct the acceptance within the time specified in the Contract, Party A shall inform PartyB without delay and determine another date for the acceptance. Party A, however, shall admit the completion date of the Decoration Project and be liable for the expenses for taking care of the construction by Party B and other relevant expenses.6. Contract Prices & Settlement6.1The Parties agree to determine the contract price pursuant to mode ????below:(1) Fixed price(2) Fixed price, combined with / % risk rate (including / )(3) Adjustable price: make adjustments and settlement according to relevant state regulations6.2Party A shall make payments after the Contract comes into effect. Final payment will be made after completion of the project.6.3After final acceptance of construction, Party B will make the engineering settlement and transfer the relevant documents to Party A. Party A shall complete reviewing of the documents within / days. Where Party A fails to raise an objection, its consent?shall?be deemed?to have been given. The final payment shall be made within / days.7. Material supplies7.1 Party A is in charge of purchasing the supplied materials and equipments (refer to Annex). The materials shall be qualified and meet the design requirements, and be delivered to the scene in time. If Party B is responsible for picking up the materials, Party A shall hand over delivery documents to Party B and let Party B bear the transportation expense. Party A shall be responsible for the damages to the project caused by quality problems or specification differences of the materials and equipment supplied by Party A. Party B is responsible for storage of materials provided by Party A, and Party A shall pay / % of the material value as the storage fee. Party B shall be responsible for the compensation associated with the loss caused by improper storage of Party B.7.2Materials?provided?by?Party?B:?Any?materials?or?equipment?supplied?by?P arty?B?which?do?not?meet?the?design?and?construction?requirements?are?prohibit ed.?If the materials have been used, the loss caused shall be assumed by Party B.8. Safe Production and Fire Regulations8.1 Construction drawings provided by Party A or practice that should comply with the fire regulations of the People's Republic of China and the relevant fire safety rules.8.2Party B should strictly abide by Engineering Safety Technical Regulations for Construction and Installation, Safety Operation Procedures,Fire Control Regulation and other relevant laws and regulations.8.3 Party A shall bear all the resulting economic losses if the drawings or instructions violate the safety operating rules, fire control and fire prevention design specifications.8.4 Party B shall bear all the resulting economic losses if its construction process violates the safety operating rules, fire control and fire preventiondesign specifications.9. Rewards and Liabilities for Breach of the Contract9.1If Party A causes any delays to the completion of this project, then PartyA must pay to PartyB for each day beyond the scheduled completion date.A fine of will be imposed in respect of each day that the payment is overdue.9.2If Party B causes any delays to the completion of this project, then PartyB must pay to Party A for each day beyond the scheduled completion date. If the project needs to be completed ahead of the time limit, a reward of will be provided by Party A in respect of each day before the scheduled completion date.9.3 If all or parts of the project reach to the excellent standard, Party A will pay to Party B as a reward.9.4 Party B shall protect the equipments provided by Party A, furniture, furnishings and finished products placed on site. If losses are caused, Party B shall bear the compensation responsibility.9.5If Party A instructs Party B to make any alterations to a load bearing wall and Party A has not sought and received permission from the building property management, Party A shall be responsible for any resulting costs and shall indemnify Party B for any additional expenses incurred.9.6If Party B makes any unauthorized changes to load bearing walls or building pipelines and such changes result in damages or loss, it shall be the responsibility of Party B to pay for such loss.9.7 Party A shall be responsible for any extra costs incurred due to his use of the property before the final completion meeting and signing of the “Engineering Quality Acceptance” document.9.8If a party suspends its performance, it shall timely notify the other partyand be liable for all losses thus incurred to the other party.10. Deputes10.1If there is any dispute between the two parties, the parties should solve through negotiation or submit any disputes to the relevant departments without influencing the project progress.10.2 If the parties are reluctant to settle the dispute through consultation or mediation or they fail in settling the dispute thereby, they may apply to Changzhou Arbitration Committee for arbitration in accordance with the arbitral clause in the contract or in accordance with the written arbitration agreement reached between them subsequently. The parties concerned may bring the action directly before the people's court in the absence of an arbitration clause in the contract or in the absence of a written arbitration agreement concluded afterwards.11. Final Clauses12. Supplementary Provisions12.1 Project quality warranty or insurance shall be settled by both parties through concluding agreement.12.2This contract will be printed and signed in duplicate and each party shall keep 1 copy.12.3 This Contract shall automatically terminate and expire upon the full performance12.4 Annex(1) Construction drawings or instructions(2) Project schedule(3) Project budget statement(4) List of materials provided by Party A(5) Meeting minutes(6) Design changes(7) OthersParty A (Stamp): Party B (Stamp):。

Contract for Decorative ConstructionThis Contract (the "Contract") is made and entered into as of [Date], by and between [Client Name] ("Client"), a [Client's jurisdiction] corporation with a principal place of business at [Client's address], and [Contractor Name] ("Contractor"), a [Contractor's jurisdiction] corporation with a principal place of business at [Contractor's address].1. Scope of WorkThe Contractor agrees to perform all necessary work (the "Work") for the Client in accordance with the terms and specifications set forth in this Contract, including, but not limited to, the installation of wallpaper, painting, flooring, and other decorative elements as specified by the Client. The Contractor shall use reasonable efforts to complete the Work within the timeframe specified by the Client, but time shall not be of the essence unless specifically stated otherwise in this Contract.2. Payment TermsThe Client agrees to pay the Contractor the total contract price of [Price] (the "Contract Price"), as set forth in the attached Schedule A, within the terms specified in this Contract. The Client shall make the first payment of [Percentage] of the Contract Price upon execution of this Contract, and the remaining balance shall be paid upon completion of the Work, subject to the Client's approval of the Work as set forthin Section 4 below.3. Changes to Scope of WorkIf the Client requests changes to the scope of work, including, but not limited to, changes in materials, design, or specifications, the Contractor shall provide the Client with a written estimate of the additional costs or savings resulting from such changes. The Client may approve or disapprove such changes in writing. If the Client approves the changes, the Contractor shall make the necessary adjustments to the Work and this Contract, and the Client shall be responsible for the additional costs or savings as set forth in the written estimate. If theClient disapproves the changes, the Contractor shall continue with the original scope of work as specified in this Contract.4. Approval of WorkUpon completion of the Work, the Client shall have the right to inspect and approve the Work. If the Client is not satisfied with the Work, the Contractor shall, at the Contractor's sole expense, correct any deficiencies in the Work and make any necessary adjustments to ensure that the Work meets the Client's approval. The Client shall notify the Contractor in writing of any deficiencies or adjustments required within [Number] days after the completion of the Work.5. WarrantyThe Contractor warrants that the Work shall be free from defects in materials and workmanship for a period of [Warranty Period] from the date of completion of the Work. If the Client notifies the Contractor in writing of any defects or failures to conform to the specifications within [Warranty Period], the Contractor shall, at the Contractor's sole expense, correct any such defects or failures. The Contractor's sole liability under this warranty shall be limited to the cost of correcting the defects or failures. The Contractor shall not be liable for any incidental, consequential, or punitive damages under this warranty.6. IndemnificationThe Contractor agrees to indemnify and hold the Client harmless from and against any and all claims, losses, damages, liabilities, and expenses (including, without limitation, attorney's fees and costs) arising out of or in connection with the performance of the Work, except to the extent such claims, losses, damages, liabilities, and expenses are directly caused by the Client's actions or omissions.7. Default and TerminationIf either party defaults in the performance of any material obligation under this Contract and such default continues for [Number] days after written notice thereof from the other party, the other party mayterminate this Contract by written notice. In the event of termination, the Client shall pay the Contractor for the Work performed up to the date of termination, subject to the Client's approval of the Work as set forth in Section 4 above.8. Governing Law and Dispute ResolutionThis Contract shall be governed by and construed in accordance with the laws of the [Governing Jurisdiction]. Any disputes arising out of or in connection with this Contract shall be resolved by arbitration in accordance with the rules of the [Arbitration Association], and the decision of the arbitrator(s) shall be final and binding upon the parties.9. Entire AgreementThis Contract constitutes the entire agreement between the Client and the Contractor with respect to the subject matter hereof and supersedes all prior agreements, understandings, negotiations, and discussions, whether oral or written, of the parties. This Contract may be。