建设部施工总承包合同英文版

英文建筑合同模板Building Contract Template。

This Building Contract ("Contract") is made and entered into as of [Date], by and between [Builder Name], with a principal place of business at [Address] ("Builder"), and [Owner Name], with a principal place of residence at [Address] ("Owner").1. Scope of Work。

Builder agrees to provide all labor, materials, equipment, and services necessary for the construction of [Description of Project] ("Project") in accordance with the plans and specifications attached hereto as Exhibit A. Builder shall complete the Project in a good and workmanlike manner, in compliance with all applicable laws, regulations, and codes.2. Payment。

Owner agrees to pay Builder the total contract price of [Total Contract Price] for the completion of the Project. The payment shall be made in installments as follows:a. [Percentage]% of the total contract price upon the execution of this Contract;b. [Percentage]% of the total contract price upon completion of [Milestone 1];c. [Percentage]% of the total contract price upon completion of [Milestone 2];d. [Percentage]% of the total contract price upon substantial completion of the Project; and。

建筑工程英文合同范本CONTRACT FOR CONSTRUCTION PROJECTThis Contract (the "Contract") is made and entered into as of _______________ (the "Effective Date"), and between ____________________ (the "Owner"), a corporation organized and existing under the laws of ____________________, and____________________ (the "Contractor"), a corporation organized and existing under the laws of ____________________.Article 1: Description of Work1.1 The Contractor agrees to perform all construction services (the "Work") as described in the attached Project Description (the "Project Description"), which is incorporated into and made a part of this Contract this reference.1.2 The Work shall be performed at the following location:____________________ (the "Project Site").Article 2: Scope of Work2.1 The Contractor shall perform the Work in accordance with the plans and specifications set forth in the Project Description, and in accordance with all applicable laws, regulations, and industry standards.2.2 The Contractor shall use reasonable efforts to plete the Work on or before the Completion Date (as defined in Article 5), but flure to do so shall not be considered a breach of this Contract, unless otherwise provided in this Contract.Article 3: Contract Price3.1 The Contractor agrees to perform the Work for a total contract price of ____________________ USD (the "Contract Price").3.2 The Contract Price shall be pd the Owner to the Contractor in accordance with the payment terms set forth in Article 6.Article 4: Changes to the Work4.1 The Owner or its authorized representative may request changes to the Work from time to time.4.2 Any requested changes to the Work shall be submitted the Owner to the Contractor in writing.4.3 The Contractor shall, within a reasonable time after receiving a request for changes, provide the Owner with a written estimate of the additional cost and time required to make such changes.4.4 The Owner shall have the right to accept or reject the Contractor's estimate. If the Owner accepts the Contractor's estimate, the changes shall be made as agreed upon the parties.Article 5: Completion Date and Extension5.1 The Work shall be deemed pleted when the Contractor has fully performed all of its obligations under this Contract, and the Work has been accepted the Owner in accordance with the terms of this Contract.5.2 The Completion Date shall be _______________ (the "Original Completion Date").5.3 If the Contractor is unable to plete the Work the Original Completion Date, the Contractor may request an extension of time from the Owner.5.4 The Owner shall have the right to grant or deny the Contractor's request for an extension of time. If the Owner grants the Contractor's request, the Contractor shall be given a new Completion Date, which shall be agreed upon the parties.Article 6: Payment Terms6.1 The Contract Price shall be pd the Owner to the Contractor in accordance with the following schedule:____________________% of the Contract Price upon execution of this Contract ____________________% of the Contract Price upon pletion of the foundation work____________________% of the Contract Price upon pletion of the framing work ____________________% of the Contract Price upon pletion of the mechanical, electrical, and plumbing systems____________________% of the Contract Price upon pletion of the interior finishes____________________% of the Contract Price upon final acceptance of the Work the Owner6.2 The Contractor shall provide the Owner with a detled invoice for each payment, which shall be pd the Owner within 30 days after receipt of such invoice.Article 7: Warranties7.1 The Contractor warrants that the Work shall be performed in a workmanlike manner and in accordance with the plans and specifications set forth in the Project Description.7.2 The Contractor warrants that all materials used in the Work shall be of good quality and suitable for the intended purpose.7.3 The Contractor warrants that the Work shall be free from defects in materials and workmanship for a period of _______________ years after the date of final acceptance of the Work the Owner.Article 8: Indemnification8.1 The Contractor shall indemnify and hold harmless the Owner agnst any and all clms, losses, damages, liabilities, and expenses (including reasonable attorney's fees) arising out of or in connection with。

中英文工程总承包合同示范文本English:This Engineering, Procurement, and Construction (EPC) Turnkey Contract (the "Contract") is entered into on [Date] by and between [Party Name], hereinafter referred to as the "Contractor", and [Party Name], hereinafter referred to as the "Owner". The Contractor shall provide all labor, materials, equipment, and services necessary forthe completion of the engineering and construction of the project as described in Exhibit A (the "Project"). The Contractor shall also be responsible for obtaining all necessary permits and licenses, as wellas ensuring compliance with all applicable laws and regulations. The Owner shall provide the Contractor with access to the site and all necessary support and assistance to facilitate the timely and successful completion of the Project. The Contract Price for the completion of the Project shall be as specified in Exhibit B, payable in accordance with the terms and conditions set forth in the Contract.中文翻译:这份工程、采购和建设（EPC）总承包合同（以下简称“合同”）是由[日期]由以下各方（以下简称“承包商”）和[ Party Name]（以下简称“业主”）签署的。

施工合同中英文模板CONSTRUCTION CONTRACTTHIS CONTRACT is made and entered into as of [Insert Date], by and between [Insert Client Name], hereinafter referred to as "Client," and [Insert Contractor Name], hereinafter referred to as "Contractor."1. SCOPE OF WORKThe Contractor agrees to perform the construction services described in the attached Statement of Work (SOW) for the project identified as [Insert Project Name].2. CONTRACT AMOUNTThe total contract price for the work described in the SOW is [Insert Total Contract Price]. This price includes all labor, materials, equipment, and services necessary to complete the work.3. PAYMENT TERMSThe Client shall make payments to the Contractor as follows: a. [Insert Percentage] percent of the total contract price upon signing of this contract.b. [Insert Percentage] percent of the total contract price upon completion of [Insert Milestone].c. The remaining balance upon satisfactory completion of the work and acceptance by the Client.4. SCHEDULEThe work shall commence on [Insert Start Date] and be completed by [Insert Completion Date].5. PERFORMANCE BONDThe Contractor shall provide a performance bond in the amount of [Insert Bond Amount] to guarantee the completion of the work.6. WARRANTYThe Contractor warrants that all work will be performed in a professional and workmanlike manner and in accordance with the SOW.7. TERMINATIONEither party may terminate this contract for cause upon written notice to the other party if there is a material breach of any of the terms of this contract.8. DISPUTESAny disputes arising out of or in connection with this contract shall be resolved by [Insert Method of Dispute Resolution, e.g., arbitration, mediation, etc.].9. APPLICABLE LAWThis contract shall be governed by and construed in accordance with the laws of [Insert Jurisdiction].10. ENTIRE AGREEMENTThis contract, including the attached SOW and any exhibits, constitutes the entire agreement between the parties andsupersedes all prior negotiations, representations, and agreements.11. AMENDMENTSThis contract may be amended only in writing signed by both parties.12. NOTICESAll notices required or permitted by this contract shall be in writing and delivered to the addresses set forth below or to such other addresses as either party may designate in writing.Client: [Insert Client Name and Address]Contractor: [Insert Contractor Name and Address]IN WITNESS WHEREOF, the parties have executed this contract as of the date first above written.CLIENT[Insert Client Name]By: [Insert Authorized Signature]CONTRACTOR[Insert Contractor Name]By: [Insert Authorized Signature]Title: [Insert Title]STATEMENT OF WORK (SOW)1. PROJECT DESCRIPTIONA detailed description of the project, including the objectives, deliverables, and any specific requirements.2. WORK SCHEDULEA detailed schedule of the work, including milestones and deadlines.3. QUALITY REQUIREMENTSThe quality standards that the work must meet.4. SAFETY REQUIREMENTSSafety protocols and procedures that must be followed during the project.5. SUBMISSIONSA list of all documents, reports, or other submissions required from the Contractor.6. INSPECTION AND ACCEPTANCEProcedures for the Client's inspection of the work and acceptance of the project.7. CHANGE ORDERSProcedures for requesting and implementing changes to the scope of work.8. COMPLETION AND FINAL PAYMENTCriteria for determining when the work is complete and the conditions for final payment.9. WARRANTY AND MAINTENANCEDetails of any warranties provided by the Contractor and any maintenance services included.10. ADDITIONAL TERMSAny other specific terms and conditions relevant to the project.Please note that this is a template and should be reviewed by a legal professional to ensure it meets the specific needs and legal requirements of your project.。

工程总包合同中英双语【合同名称】Contract Name: Engineering General Contract【甲方】arty A: [填写甲方名称]【乙方】arty : [填写乙方名称]【合同编号】Contract No.: [填写合同编号]【签订日期】Date of Signing: [填写签订日期]【合同】Main ody of the Contract:第一条合同目的Article 1 urose of the Contract本合同旨在规定甲乙双方就[具体工程名称]项目的建设、管理及验收等事宜达成的共同条款。

The urose of this contract is to stiulate the common terms and conditions regarding the construction, management, and accetance of the [secific roject name].第二条合同范围与内容Article 2 Scoe and Content of the Contract本合同包括但不限于工程设计、材料采购、施工、安装、调试、验收以及保修等服务。

This contract includes, ut is not limited to, engineering design, material rocurement, construction, installation, commissioning, accetance, and warranty services.第三条合同价格Article 3 Contract rice合同总价为[金额]美元，具体支付方式和条件如下所述。

The total contract rice is [amount] US dollars, with secific ayment methods and conditions detailed elow.第四条工期与进度Article 4 Construction eriod and rogress工程预计开工日期为[具体日期]，竣工日期为[具体日期]。

建设工程合同英文Title: Construction Engineering Contracts。

Construction engineering contracts are essential documents that outline the terms and conditions of a construction project. These contracts are crucial for ensuring that all parties involved in the project understand their responsibilities and obligations.The construction engineering contract typically includes details such as the scope of work, project timeline, payment terms, and dispute resolution procedures. It also outlines the roles and responsibilities of the owner, contractor, and any other parties involved in the project.One of the key elements of a construction engineering contract is the scope of work. This section clearly defines the work to be performed, including the specific tasks, materials, and equipment required for the project. By clearly outlining the scope of work, the contract helps to prevent misunderstandings and disputes during the construction process.The project timeline is another important aspect of a construction engineering contract. This section outlines the start and completion dates of the project, as well as any milestones or deadlines that need to be met. Having a clear timeline in the contract helps to ensure that the project stays on track and is completed in a timely manner.Payment terms are also a critical component of construction engineering contracts. This section specifies the payment schedule, including the amount and timing of payments to be made to the contractor. It also outlines any penalties or incentives related to meeting project deadlines or milestones.In addition to these key elements, construction engineering contracts also include provisions for dispute resolution. This section outlines the procedures to be followed in the event of a dispute between the parties involved in the project. By including these provisions in the contract, potential conflicts can be resolved in a fair and efficient manner.In conclusion, construction engineering contracts play a vital role in ensuring the success of construction projects. By clearly outlining the scope of work, project timeline, payment terms, and dispute resolution procedures, these contracts provide a solid foundation for the successful completion of construction projects. It is essential for all parties involved in a construction project to carefully review and understand the terms of the contract before signing, in order to avoid any potential issues or disputes down the line.。

Contract for Engineering ConstructionThis Contract for Engineering Construction (the "Contract") is made and entered into as of [Date], by and between [Contractor's Name], a corporation organized and existing under the laws of [Country/State] ("Contractor"), and [Owner's Name], a individual/corporation organized and existing under the laws of [Country/State] ("Owner").1. Scope of WorkThe Contractor agrees to perform all the engineering construction services (the "Work") as described in the attached Scope of Work document (the "Scope of Work") and as further detailed in the Contract Documents. The Work shall be performed at the project site located at [Project Location].2. TermThe term of this Contract shall commence on the date hereof and shall continue until the completion of the Work, subject to the terms and conditions set forth herein. The Contractor agrees to complete the Work within [Number] days from the commencement date, unless the time for completion is extended in writing by the Owner.3. PaymentThe Contractor shall be paid for the Work performed under this Contract in accordance with the payment terms set forth in the Scope of Work. The Contractor shall submit invoices to the Owner for payment of the Work performed, and the Owner shall make payments to the Contractor within [Number] days after receipt of such invoices.4. Changes to the WorkThe Owner may, at any time during the performance of the Work, order changes to the Work. The Contractor agrees to promptly comply with any such changes, and to make any necessary adjustments to the schedule, budget, and other terms of the Contract to reflect such changes. Any changes to the Work shall be documented in writing and signed by both parties.5. Default and TerminationIf either party defaults in the performance of any obligation under this Contract, the non-defaulting party may terminate this Contract upon written notice to the defaulting party. In the event of termination, the Contractor shall be entitled to payment for the Work performed up to the date of termination, less any amounts owed to the Contractor by the Owner.6. Dispute ResolutionAny disputes arising out of or in connection with this Contract shall be resolved by arbitration in accordance with the rules of the [Arbitration Institution]. The decision of the arbitrator(s) shall be final and binding upon the parties.7. Governing Law and JurisdictionThis Contract shall be governed by and construed in accordance with the laws of [Country/State]. Any legal action or proceeding arising out ofor in connection with this Contract shall be brought exclusively in the courts of [Country/State].8. Entire AgreementThis Contract constitutes the entire agreement between the parties with respect to the subject matter hereof and supersedes all prior agreements, understandings, negotiations, and discussions, whether oral or written, of the parties.IN WITNESS WHEREOF, the parties have executed this Contract as of the date first above written.[Contractor's Name] [Owner's Name]By: \_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_ By:\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_Name: \_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_ Name: \_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_Title: \_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_ Title: \_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_Address: \_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_ Address: \_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_Date:\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_ \_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\。

xxxx施工合同Construction Contract of xxxx发包方（甲方）xxxxParty A: xxxx承包方（乙方）xxxxParty B: xxxx本合同由如上列明的甲、乙双方按照《中华人民共和国合同法》、《建筑安装工程承包合同条例》以及国家相关法律法规的规定，结合本合同具体情况，于xx年x月x日在xx签订。

This contract is signed by the two Parties in xxxx on xxxx according to the “Contract Law of the People’s Republic of China”, the “Regulation on Building and Installation Contracting Contract”, and other relevant national laws and regulations, as well as the specific nature of this project第一条总则Article 1 General Principles1.1合同文件Contract Documents本合同包含合同、展示、施工图纸、作法说明、招投标文件以及合同所指的其他文件，它们均被视为合同的一部分。

合同文件应该能够相互解释，互为说明。

组成本合同的文件及优先解释的顺序如下：本合同、中标通知书、投标书及其附件、标准、规范及有关技术文件、图纸、工程量清单及工程报价单或预算书。

合同履行中，发包人承包人有关工程的洽商、变更等书面下一或文件视为本合同的组成部分。

This contract includes the contract itself, exhibits, construction drawings, explanations of work procedures, tender documents, as well as other documents specified by the contract. The contract documents should be mutually explainable and mutually descriptive. The documents that constituted the contract and the priority hierarchy of explanations of the documents are as follows: this contract; the official letter of winning the tender; Letter of bidding and its annex, standards, guidelines, and relevant technical documents, drawings, Bill of Quantity (BOQ), quotation of prices, and project budget. During the implementation of the contract, any written agreements or documents between two parties such as change-orders are also regarded will be deemed as part of this contract.1.1.1项目概况Project Introduction1.1.2工程名称：xxxxName of Project: xxxx1.1.3工程地点：xxxxLocation of Project: xxxx1.1.3.1工程范围：除了本合同其他条款另有说明外，乙方应提供为履行合同所需的所有服务，用品以及其他保障工程进行所需的必要花费以完成下列工作：Scope of the project: unless otherwise explained by other articles in this contract, Party B shall provide all services, utensils, and other necessary cost for the implementation of this contract; the scope of project includes, but not limited to:※室内装饰工程，详见附件一和附件二Inner decoration, see appendix 1 & 2※室外装饰工程（门窗、屋面、台阶等），详见附件一和附件二Façade(including doors, windows, roof and stairs) see appendix 1 & 2※电器工程，详见附件一和附件二Electronic Engineering, see appendix 1 & 2※空调工程，详见附件一和附件二Air Conditioning System, see appendix 1 & 2※给排水及采暖工程，详见附件一和附件二Water Supply, Sewage and Heating System, see appendix 1 & 2※消防工程Fire Control System, see appendix 1 & 2※其他图纸上所列项目（任何对原定设计的变更应提供新的图纸并有甲方的签字确认）以上所有的工程项目以下统称为“工程”。

Contract for Construction WorkThis Contract (the "Contract") is made and entered into as of [Date], by and between [Client Name] ("Client"), a [Client's jurisdiction] corporation, and [Contractor Name] ("Contractor"), a [Contractor's jurisdiction] corporation.1. Scope of WorkThe Contractor agrees to perform all construction work (the "Work") as described in the attached Schedule A (the "Scope of Work"), which is incorporated into this Contract by reference. The Work shall be performed at the construction site located at [Location], as more particularly described in the Scope of Work.2. TermThe term of this Contract shall commence on the date hereof and shall continue until the Work is completed, or until the parties otherwise agree in writing to terminate this Contract (the "Term").3. Price and Payment Terms3.1 PriceIn consideration for the performance of the Work, the Client shall pay the Contractor the total amount of [Price], as set forth in the Scope of Work.3.2 Payment TermsThe Client shall make payments to the Contractor as follows:(a) [Percentage] of the total price shall be paid upon the signing of this Contract;(b) [Percentage] of the total price shall be paid upon the completion of [specify percentage of Work];(c) The remaining [Percentage] of the total price shall be paid upon the final completion of the Work, subject to the Client's approval as set forth in Section 6 below.4. Performance and Completion4.1 PerformanceThe Contractor shall perform the Work in accordance with the terms of this Contract, the applicable specifications and drawings, and all applicable laws, regulations, and standards.4.2 CompletionThe Contractor shall use commercially reasonable efforts to complete the Work on or before the completion date set forth in the Scope of Work (the "Completion Date"). The Contractor shall be responsible for any delays in completion of the Work, whether directly or indirectly caused by the Contractor's actions or inactions.5. WarrantiesThe Contractor warrants that the Work shall be performed in a workmanlike manner and in accordance with the applicable specifications and drawings. The Contractor further warrants that the Work shall be free from defects in materials and workmanship for a period of [Warranty Period], following the final completion of the Work.6. Approval of WorkThe Client reserves the right to inspect and approve the Work at any time during the performance of the Work. The Client's approval of the Work shall be deemed to have been given if the Client fails to object in writing to the Work within [specify number of days] after its completion.7. Default and Termination7.1 DefaultIf either party defaults in the performance of any material obligation under this Contract, the non-defaulting party may terminate this Contract by written notice to the defaulting party.7.2 Termination for ConvenienceThe Client may terminate this Contract at any time for any reason or no reason, upon written notice to the Contractor. In the event of such termination, the Contractor shall be entitled to payment for the Work performed up to the date of termination, subject to the Client's right to withhold any amounts due to the Contractor's default under this Contract.8. Dispute ResolutionAny disputes arising out of or in connection with this Contract shall be resolved by arbitration in accordance with the rules of the [Arbitration Association], and the decision of the arbitrator(s) shall be final and binding upon the parties.9. Governing LawThis Contract shall be governed by and construed in accordance with the laws of the [Governing Jurisdiction].10. Entire AgreementThis Contract constitutes the entire agreement between the parties with respect to the subject matter hereof, and supersedes all prior agreements, understandings, negotiations, and discussions, whether oral or written, of the parties.IN WITNESS WHEREOF, the parties have executed this Contract as of the date first above written.[Client Name] [Contractor Name]By:\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_ \_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_ \_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_ \_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_ \_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_ \_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_ \_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_ \_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_ \_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_ \_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_ \_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_ \_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_ \_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_ \_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_ \_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_ \_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_ \_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_ \_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_ \_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_ \_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_ \_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_ \_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_ \_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_ \_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_ \_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_ \_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_ \_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_ \_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_ \_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\。

英语建筑工程合同范本---CONTRACT FOR CONSTRUCTION ROJECTThis Agreement is made on [Date] etween:Emloyer (Client):Name: [Full Name]Address: [Address]Reresented y: [Reresentative's Name]Contractor:Name: [Full Name]Address: [Address]Reresented y: [Reresentative's Name]1. roject Details:The Contractor agrees to construct the following roject for the Emloyer:- roject Name: [roject Name]- Location: [Location]- Descrition: [Detailed descrition of the roject including dimensions, materials, and secific requirements]2. Scoe of Work:The Contractor shall rovide all laor, materials, tools, and equiment necessary for the comletion of the roject. The secific scoe of work includes:- [List of tasks and deliverales]- Comliance with all alicale uilding codes and regulations3. Contract Sum:The total contract sum for the roject is [Amount in words and figures]. This sum is inclusive of all costs associated with the construction.4. ayment Terms:- Advance ayment: [Amount] due uon signing of the contract.- rogress ayments: [Details of ayments ased on milestones or rogress]- Final ayment: [Amount] uon comletion and aroval of the roject.5. Timeline:The roject must e comleted y [Comletion Date]. Interim deadlines may aly for secific hases of the roject.6. Change Orders:Any changes to the original scoe of work will e documented in a change order and agreed uon y oth arties efore imlementation.7. Warranty and Defects Liaility:The Contractor warrants that the work will e free from defects in material and workmanshi for a eriod of [Warranty eriod]. Any defects identified during this eriod must e rectified y the Contractor at no additional cost to the Emloyer.8. Insurance:The Contractor shall maintain aroriate insurance coverage for the roject, including liaility insurance and workers' comensation.9. Termination:Either arty may terminate the contract for reach or if the roject is delayed eyond a reasonale eriod.10. Disute Resolution:Any disutes arising out of or in connection with this contract shall e resolved through negotiation. If negotiation fails, the arties agree to sumit the disute to [Method of resolution,e.g., mediation, aritration, or court roceedings].11. Governing Law:This contract shall e governed y and construed in accordance with the laws of [Jurisdiction].12. Entire Agreement:This contract constitutes the entire agreement etween the arties and suersedes any rior negotiations, reresentations, or agreements.IN WITNESS WHEREOF,The arties have executed this contract as of the date first aove written.Emloyer (Client): [Signature] [rinted Name][Date]Contractor: [Signature] [rinted Name][Date]---。

建设工程施工合同示范文本英文版英文回答：Construction Engineering Construction Contract Model Text.Article 1 General Provisions.1.1 This contract is a construction engineering construction contract (hereinafter referred to as the "Contract") signed by and between the Party A (hereinafter referred to as the "Employer") and the Party B (hereinafter referred to as the "Contractor").1.2 The subject matter of this Contract is the construction project of the____________________________________ (hereinafter referred to as the "Project").1.3 The construction site of the Project is located at_________________________________________________.1.4 The construction period of the Project is from_______________ to _______________.1.5 The total contract price of the Project is RMB________________ (in Chinese characters: ________________).Article 2 Obligations of the Employer.2.1 The Employer shall provide the Contractor with the construction design documents, technical specifications, and other relevant technical materials within_______________ days after the signing of this Contract.2.2 The Employer shall pay the Contractor the contract price in accordance with the agreed payment terms.2.3 The Employer shall cooperate with the Contractor in the construction of the Project and provide necessary assistance.2.4 The Employer shall supervise the Contractor's performance of the Contract and have the right to inspect the Project's progress and quality.2.5 The Employer shall accept the completed Project and issue a written acceptance certificate within_______________ days after the Contractor submits the竣工验收报告（Completion Acceptance Report）.Article 3 Obligations of the Contractor.3.1 The Contractor shall construct the Project in accordance with the construction design documents,technical specifications, and other relevant technical materials provided by the Employer.3.2 The Contractor shall complete the Project within the agreed construction period and ensure the quality of the Project.3.3 The Contractor shall be responsible for the safety of the construction site and the construction personnel.3.4 The Contractor shall cooperate with the Employer in the construction of the Project and accept the Employer's supervision.3.5 The Contractor shall submit the竣工验收报告（Completion Acceptance Report）to the Employer within_______________ days after the completion of the Project.Article 4 Payment Terms.4.1 The Employer shall pay the Contractor the contract price in installments. The specific payment terms are as follows:4.1.1 Within _______________ days after the signing of this Contract, the Employer shall pay the Contractor_______________% of the contract price as an advance payment.4.1.2 Within _______________ days after the Contractor completes _______________% of the Project, the Employershall pay the Contractor _______________% of the contract price....Article 5 Dispute Resolution.5.1 Any dispute arising from this Contract shall be resolved through negotiation. If negotiation fails, either party may submit the dispute to arbitration in accordance with the arbitration rules of the _______________ Arbitration Commission.5.2 The arbitration award shall be final and binding on both parties.Article 6 Miscellaneous Provisions.6.1 This Contract shall come into effect on the date of signing and shall be valid until the completion of the Project and the fulfillment of all obligations under this Contract.6.2 Any amendment to this Contract shall be made in writing and signed by both parties.6.3 This Contract is made in _______________ copies, with each party holding _______________ copies.中文回答：建设工程施工合同示范文本。

施工合同范本英文版CONSTRUCTION CONTRACTThis Construction Contract (the "Contract") is made and entered into on the date of _____________ ("Effective Date")by and between _____________ ("Owner"), with its principal place of business at _____________, and _____________ ("Contractor"), with its principal place of business at_____________.1. PROJECT DESCRIPTIONThe Contractor shall perform the construction services (the "Project") as described in the attached Scope of Work ("SOW"), which is incorporated herein by reference.2. CONTRACT PRICEThe total contract price for the Project is $_____________ ("Contract Price"), which includes all labor, materials, equipment, and other costs necessary to complete the Projectin accordance with the SOW.3. PAYMENT TERMSThe Owner shall make payments to the Contractor as follows:a. A deposit of _____________ percent of the ContractPrice shall be due upon execution of this Contract.b. Progress payments shall be made upon the completion of each milestone as set forth in the SOW.c. The final payment shall be due upon substantialcompletion of the Project, subject to the deduction of any retainage as provided in this Contract.4. RETAINAGEThe Owner shall retain _____________ percent of each progress payment, which shall be released to the Contractor upon the Owner's receipt of a final inspection certificate and the expiration of the applicable warranty period.5. PERFORMANCE BONDThe Contractor shall provide a performance bond in the amount of _____________ percent of the Contract Price, issued by a surety company acceptable to the Owner, to ensure thefaithful performance of the Contractor's obligations under this Contract.6. WARRANTYThe Contractor warrants that all work performed under this Contract shall be free from defects in materials and workmanship for a period of _____________ years from the date of substantial completion.7. CHANGE ORDERSAny changes to the scope of work or the Contract Price shall be documented in writing and signed by both parties (a "Change Order"). The Contractor shall provide a revised SOW and Contract Price for any approved Change Order.8. DEFAULTIn the event of a default by either party, the non-defaulting party may terminate this Contract upon written notice and mayseek damages in accordance with applicable law.9. DISPUTE RESOLUTIONAny disputes arising out of or relating to this Contractshall be resolved by arbitration in accordance with the rules of the American Arbitration Association.10. APPLICABLE LAWThis Contract shall be governed by and construed in accordance with the laws of the State of _____________.11. ENTIRE AGREEMENTThis Contract, including all attachments and exhibits, constitutes the entire agreement between the parties and supersedes all prior negotiations, understandings, and agreements, whether written or oral.12. AMENDMENTSThis Contract may not be amended or modified except inwriting signed by both parties.IN WITNESS WHEREOF, the parties have executed this Contract as of the date first above written.Owner: ______________________________Contractor: ______________________________By: _____________________________ By:_______________________________Name: _____________________________ Name:_______________________________Date: _____________________________ Date: _______________________________。

英文施工合同范本Construction ContractThis Construction Contract ("Contract") is entered into as of [Insert Date] between [Insert Name of Contractor], a [Insert Type of Entity] with a principal place of business at [Insert Address of Contractor] ("Contractor"), and [Insert Name of Client], a [Insert Type of Entity] with a principal place of business at [Insert Address of Client] ("Client").1. Scope of WorkThe Contractor agrees to perform the construction services ("Work") as detailed in the attached Scope of Work document, which is hereby incorporated by reference.2. Payment TermsThe Client shall pay the Contractor for the Work performed in accordance with the following schedule:- A deposit of [Insert Percentage]% of the total contract price upon execution of this Contract.- [Insert Payment Schedule Details, e.g., Milestone Payments, Progress Payments, etc.].3. Commencement and CompletionThe Work shall commence on [Insert Date] and is expected to be completed by [Insert Date]. The Contractor shall use all reasonable efforts to complete the Work within the agreedtimeframe.4. DelaysIn the event of any delay in the commencement or completion of the Work, the Contractor shall promptly notify the Client in writing, detailing the cause of the delay and any proposed measures to mitigate the impact of the delay.5. Quality AssuranceThe Contractor warrants that all Work will be performed in a professional and workmanlike manner and will conform to the standards of good workmanship and the requirements of the applicable building codes and regulations.6. Changes and VariationsAny changes or variations to the Work must be agreed upon in writing by both parties and shall be subject to additional cost and time adjustments as appropriate.7. Health and SafetyThe Contractor shall comply with all applicable health and safety laws and regulations and shall take all reasonable steps to ensure the safety of all persons on the construction site.8. InsuranceThe Contractor shall maintain [Insert Type of Insurance] insurance coverage for the duration of the Contract, with minimum coverage limits of [Insert Minimum Coverage Amount].9. Warranties and GuaranteesThe Contractor warrants that all materials and workmanshipwill be free from defects for a period of [Insert Warranty Period] from the date of completion of the Work.10. Dispute ResolutionAny disputes arising out of or in connection with thisContract shall be resolved by [Insert Method of Dispute Resolution, e.g., mediation, arbitration, or litigation].11. TerminationEither party may terminate this Contract by written notice if the other party breaches any material term of this Contract and fails to cure such breach within [Insert Number of Days] days after receiving written notice of the breach.12. ConfidentialityThe parties agree to keep confidential all information obtained from the other party in connection with this Contract, except as required by law or with the prior written consent of the other party.13. Entire AgreementThis Contract constitutes the entire agreement between the parties and supersedes all prior negotiations, understandings, and agreements between the parties, whether written or oral.14. Governing LawThis Contract shall be governed by and construed inaccordance with the laws of [Insert Jurisdiction].15. NoticesAll notices under this Contract shall be in writing and shall be deemed duly given when delivered personally or by email to the addresses set forth below or to such other address as either party may designate in writing.[Insert Name of Contractor]Address: [Insert Address]Email: [Insert Email][Insert Name of Client]Address: [Insert Address]Email: [Insert Email]IN WITNESS WHEREOF, the parties have executed this Contract as of the date first above written.[Insert Name of Contractor] [Insert Name of Client]By:\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\ _\_\_\_\_Name:\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\ _\_\_\_\_By: \_\_\_\_\_\_\_\_\_。

英文施工合同范本Construction ContractThis Construction Contract (the "Contract") is made and entered into as of [date] (the "Effective Date") and between:Party A (the "Owner"):Name: [Owner's Name]Address: [Owner's Address]Contact Person: [Owner's Contact Person]Telephone Number: [Owner's Telephone Number]Party B (the "Contractor"):Name: [Contractor's Name]Address: [Contractor's Address]Contact Person: [Contractor's Contact Person]Telephone Number: [Contractor's Telephone Number]1. Project DescriptionThe Contractor shall undertake the construction project described as follows: [Project Description, including location, scope, and nature of the work]2. Project ScheduleThe Contractor shall mence the work on or before [start date] and plete the project [pletion date], subject to any extensions of time agreed upon in writing the Owner.3. Contract PriceThe total contract price for the project is $[amount] (the "Contract Price"), which shall be pd the Owner to the Contractor in accordance with the payment terms set forth in this Contract.4. Payment Terms(a) An advance payment of $[advance amount] shall be made to the Contractor within [number of days] days after the execution of this Contract.(b) Progress payments shall be made at regular intervals based on the pletion of defined milestones or stages of the project, as detled in the payment schedule attached hereto.(c) The final payment of [final payment amount] shall be made upon satisfactory pletion and acceptance of the project the Owner.5. Workmanship and MaterialsThe Contractor shall perform the work in a good and workmanlike manner and shall use materials of good quality and in accordance with the specifications and standards set forth in the project documents.6. Changes and AmendmentsAny changes or amendments to the scope of work, specifications, or contract price shall be made in writing and signed both the Owner and the Contractor.7. Inspection and AcceptanceThe Owner or its representatives shall have the right to inspect the work at reasonable intervals during the construction process. The project shall be deemed accepted upon the Owner's written confirmation of satisfactory pletion.8. WarrantiesThe Contractor warrants that the work performed under this Contract shall be free from defects in workmanship and materials for a period of [warranty period] from the date of acceptance.9. IndemnificationThe Contractor shall indemnify and hold the Owner harmless from and agnst any clms, damages, losses, or expenses arising out of or in connection with the Contractor's performance of the work.10. TerminationThis Contract may be terminated either party in the event of a material breach the other party, subject to prior written notice and an opportunity to cure the breach.11. Dispute ResolutionAny disputes arising out of or in connection with this Contract shall be resolved through amicable negotiation. If negotiation fls, the dispute shall be submitted to arbitration in accordance with the rules of [arbitration institution].12. Governing LawThis Contract shall be governed and construed in accordance with the laws of [jurisdiction].IN WITNESS WHEREOF, the parties have executed this Contract as of the date first above written.Party A (Owner): ____________________Signature: ____________________Date: ____________________Party B (Contractor): ____________________Signature: ____________________Date: ____________________。

建筑施工合同范本英语This Contract (the "Contract") is made and entered into as of the __ day of____________, 20____, by and between ____________ ("Owner"), with a mailing address of ____________, and ____________ ("Contractor"), with a mailing address of ____________.Article 1: Scope of Work1.1 The Contractor shall perform all work described in Exhibit A attached hereto and incorporated herein by reference (the "Scope of Work").1.2 The Contractor shall provide all labor, materials, equipment, and services necessary to complete the work described in the Scope of Work.1.3 The Contractor shall obtain all necessary permits and licenses required to perform the work.Article 2: Contract Price2.1 The Owner shall pay the Contractor a total contract price of ____________ Dollars ($______) for the completion of the work described in the Scope of Work.2.2 Payment shall be made in accordance with the payment schedule set forth in Exhibit B attached hereto and incorporated herein by reference.Article 3: Time for Completion3.1 The Contractor shall commence the work on ____________, 20____, and shall complete the work on ____________, 20____, subject to extensions of time as provided in this Contract.3.2 The Contractor shall be entitled to an extension of time for delays caused by reasons beyond its control, including but not limited to acts of God, strikes, and delays in the delivery of materials.Article 4: Changes in the Work4.1 The Owner may, from time to time, make changes in the Scope of Work by issuing written change orders. The Contractor shall proceed with the work described in each change order and be paid for such work in accordance with the terms of this Contract.4.2 The Contractor may propose changes in the Scope of Work by submitting written proposals to the Owner. The Owner may, in its sole discretion, accept or reject such proposals. If accepted, the changes shall be made in accordance with the terms of this Contract.Article 5: Warranties5.1 The Contractor warrants that all work performed under this Contract shall be free from defects in workmanship and materials for a period of ____________ from the date of substantial completion of the work.5.2 The Contractor shall, at its own expense, correct any defects in the work during the warranty period.Article 6: Indemnification6.1 The Contractor shall indemnify and hold harmless the Owner from and against any and all claims, damages, losses, and expenses, including but not limited to attorney's fees, arising out of or resulting from the performance of the work under this Contract, except to the extent caused by the negligence of the Owner.Article 7: Termination7.1 The Owner may terminate this Contract at any time by giving written notice to the Contractor. In the event of termination, the Contractor shall be entitled to payment for work performed up to the date of termination, in accordance with the terms of this Contract.7.2 The Contractor may terminate this Contract at any time by giving written notice to the Owner. In the event of termination by the Contractor, the Owner shall be entitled to recover from the Contractor any additional costs incurred by the Owner in completing the work.Article 8: Dispute Resolution8.1 Any disputes arising out of or related to this Contract shall be resolved by binding arbitration in accordance with the rules of the American Arbitration Association. The decision of the arbitrator shall be final and binding upon the parties.Article 9: Governing LawThis Contract shall be governed by and construed in accordance with the laws of the State of ____________.Article 10: Miscellaneous10.1 This Contract constitutes the entire agreement between the parties with respect to the subject matter hereof and supersedes all prior agreements, negotiations, and understandings, whether written or oral.10.2 This Contract may be amended or modified only by a written instrument executed by both parties.10.3 If any provision of this Contract is held to be invalid or unenforceable, the remaining provisions shall remain in full force and effect.IN WITNESS WHEREOF, the parties have executed this Contract as of the date first above written.OWNER:By: ___________________________Name:Title:Date:CONTRACTOR:By: ___________________________Name:Title:Date:。

全版的施工工程协议英文版Full Version Construction Project AgreementThis document serves as a comprehensive agreement for all construction projects between the parties involved. It outlines the terms and conditions that govern the relationship and responsibilities of each party throughout the duration of the project.Parties InvolvedThe parties involved in this agreement are the contractor, who is responsible for carrying out the construction work, and the client, who is the owner of the property or entity seeking the construction services.Scope of WorkThe scope of work includes all tasks and activities necessary for the successful completion of the construction project. This may include butis not limited to, site preparation, building construction, installation of utilities, and finishing work.TimelineThe timeline for the construction project will be clearly outlined in the agreement, including start and end dates, as well as any milestones or deadlines that need to be met throughout the project.Payment TermsPayment terms will be detailed in the agreement, including the total cost of the project, payment schedule, and any penalties for late payment or changes to the scope of work.Change OrdersAny changes to the scope of work must be documented in writing and agreed upon by both parties before being implemented. This ensuresclear communication and prevents disputes during the construction process.Insurance and LiabilityBoth parties will be required to maintain adequate insurance coverage for the duration of the project, including liability insurance to protect against any accidents or damages that may occur during construction.Dispute ResolutionIn the event of any disputes or disagreements, the parties agree to first attempt to resolve the issue through mediation or arbitration before pursuing legal action. This promotes a collaborative approach to conflict resolution.TerminationEither party may terminate the agreement in writing if the other party fails to fulfill their obligations or breaches the terms of the agreement. This ensures that both parties have an exit strategy in case the project cannot be completed as planned.Governing LawThis agreement will be governed by the laws of the state or jurisdiction where the construction project is taking place, ensuring that any legal disputes are resolved according to the local laws.This document represents the full version of the Construction Project Agreement and should be reviewed and signed by all parties involved before the start of the project.。

英文工程施工合同范本This Engineering Construction Contract (the "Contract") is entered into on [Date] by and between [Contracting Party 1], whose address is [Address], and [Contracting Party 2], whose address is [Address].RECITALS:Whereas, [Contracting Party 1] is a licensed contractor specializing in engineering construction services; andWhereas, [Contracting Party 2] desires to engage the services of [Contracting Party 1] to perform certain engineering construction services;Now, therefore, in consideration of the mutual promises and covenants contained herein, the parties agree as follows:1. Scope of Work:[Contracting Party 1] agrees to perform the engineering construction services as described in Exhibit A attached hereto and incorporated herein by reference.2. Payment:[Contracting Party 2] agrees to pay [Contracting Party 1] the total sum of [Total Amount] for the engineering construction services, payable in the following installments: [Payment Schedule].3. Timeframe:The work shall commence on [Start Date] and be completed by [Completion Date], unless otherwise agreed upon by the parties in writing.4. Changes in Scope:Any changes in the scope of work must be agreed upon by both parties in writing.5. Warranties:[Contracting Party 1] warrants that all work performed under this Contract will be done in a professional and workmanlike manner.6. Indemnification:Each party agrees to indemnify and hold harmless the other party from any claims, damages, or losses arising out of the performance of this Contract.7. Governing Law:This Contract shall be governed by and construed in accordance with the laws of [State/Country].IN WITNESS WHEREOF, the parties have executed this Contract as of the date first above written.[Contracting Party 1]By:________________________Name:_____________________Title:______________________[Contracting Party 2]By:________________________Name:_____________________Title:______________________。

施工合同中英文模板Construction ContractTHIS CONTRACT is made and entered into on the [Date] between [Contractor Name], hereinafter referred to as "Contractor," and [Client Name], hereinafter referred to as "Client."WHEREAS, the Client desires to engage the services of the Contractor for the construction of a project described as [Project Description], and the Contractor agrees to perform the work according to the terms and conditions set forth herein.NOW, THEREFORE, in consideration of the mutual promises and covenants contained herein, the parties agree as follows:1. Scope of Work: The Contractor shall provide all labor, materials, and equipment necessary to complete the work as outlined in the attached [Scope of Work] document.2. Payment Terms: The total contract price is [Total Contract Price]. The Client shall make payments to the Contractor as follows: [Payment Schedule].3. Commencement and Completion: The work shall commence on [Commencement Date] and shall be completed by [Completion Date].4. Delays: The Contractor shall not be liable for any delay caused by factors beyond its control, including but not limited to acts of God, labor disputes, or shortages of materials.5. Changes and Variations: Any changes to the work shall be documented in writing and agreed upon by both parties. The cost and time implications of such changes shall be adjusted accordingly.6. Warranties: The Contractor warrants that all work will be performed in a professional manner and will comply with all applicable laws and regulations.7. Dispute Resolution: Any disputes arising out of orrelating to this contract shall be resolved by arbitration in accordance with the rules of the [Arbitration Body].8. Termination: This contract may be terminated by either party upon written notice if the other party breaches any material term of this contract and fails to cure such breach within [Cure Period] days after receipt of written notice.9. Governing Law: This contract shall be governed by and construed in accordance with the laws of the [Jurisdiction].10. Entire Agreement: This contract, including all attachments, constitutes the entire agreement between the parties and supersedes all prior negotiations, representations, and understandings.IN WITNESS WHEREOF, the parties have executed this contract as of the date first above written.[Contractor Name]By: [Authorized Signatory]Address: [Contractor Address][Client Name]By: [Authorized Signatory]Address: [Client Address]施工合同本合同由 [日期] 签订于 [承包商名称]，以下简称“承包商”，与[客户名称]，以下简称“客户”。

Translation:Construction ContractParty A: (Developer)Party B: (Contractor)This contract is signed by the two Parties Party A and Party B according to the Contract Law of the People’s Republic of China, the Contraction law of the People’s Republic of China , and other relevant national laws and regulations, as well as the specific nature of this project. On the basis of honesty and credit, equality, voluntariness, party A and party B have reached consensus through negotiations and signed this contract.1.Project Introduction1.1 Name of Project:1.2 Location of Project: From to .1.3 Scope and content of the project: .1.4 The design of construction drawings: .2.Nature of Contracting: Contract for labor and materials .3.Construction periodThis project will take 20 days after the receive of the beginning notice from Party A (including reception time after completion),and including the beginning date and completion date.4.Quality of ProjectQuality of Project: qualified .5.Contract Amount5.1 Contract Amount: be RMB 400,000 Yuan tentatively (The actual settlement shall prevail).5.2 Adjustment of contract amount: .6.Final Audit of the project6.1 The condition and steps for Party A pay the project funds to Party B:Party A agrees to pay Party B for RMB150,000Yuan three days after the beginning of the project,the balance will be paid 97% after the qualified completion, and 3% warranty guarantee fee will be paid one years if there is no quality problem.6.2 Mode of payment: .6.3 Party B shall submit to Party A equivalent invoice before Party A’s each period payment, otherwise, Party A can refuse to pay until the receiving of t he Party B’s invoice.6.4 The invoice provided by Party B should be valid. Any falls invoice provided byParty B which are found by relevant office, the Party B should not only provide the valid invoice to Party A, but also bear the responsible caused by the invalid invoice.7.Variation of design and visa7.1During the process of the project, any contract list, technology checking list ( not include the variation, addition, substitution, and reduction on the drawings and project fee) concerning about this project shall only be regarded as effective with the confirmation of the representative Party A in writing.7.2 Any variation notice list, technology checking list, contract list, technology checking list ( include the drawings design) concerning about this project shall only be regarded as effective with the confirmation of the seal of Party A.7.3In the event of Party B fails to complete the project according to the drawing variation, Party B shall pay to Party Aas penalty for the breach.Party B will also bear the responsible and the reworking fee caused by the continued working regardless of the new design.7.4Party B shall take full responsibility for any loss caused by delaying for more than days applying for extension vise from Party A days after the receiving of changed design.8. Acceptance and Final Audit of the project8.1 Acceptance of the project8.1.1This project should meet the national quality acceptance standards and should beaccepted at the first inspection after completion. The Quality Acceptance Criteria of Construction of nation must be regarded as the acceptance standards for the project. Party B shall inform Party A in writing of all kinds of inspection and acceptance withi n 3 days.Party A shall arrange inspection and acceptance within 3 working days after receiving the notification.8.1.2Party B shall be responsible for the re-inspection cost, and the project period shall not be extended.8.2 Final Audit of the projectIf the result of re-inspection has passed acceptance standards, Party B shall submit the audit report and materials to Party A for verification within 7 days. (the materials include ).9.Obligations of Party A and Party B9.1. Obligations of Party A:9.1.1.Party A appoints as the on-site representative to supervise the fulfillment of contract obligations, to oversee the quality control and check the project progress, and to handle issues such as acceptance and variations and withdraw the representative at any time.9.1.2. Days before beginning of the project, Party A shall provide Party B .9.1.3. Party A shall confirm the variation and suggestion days after providing todesign drawings and scheme to Party B.9.1.4.Party A shall be responsible for coordinating the relationship with the engining.9.2. Obligations of Party B.Party B appoints WangZhirong as the on-site representative of Party B to take charge of fulfilling the contract obligations. The on-site representative of Party B shall organi ze the construction according to contract requirements so that the project can be comp leted according to the quality and quantity requirements and on a timely manner..Party B shall observe safetypolicies of on-site management by the state and Guangxi , Nanning government authorities and shall independently and fully assumes responsible for the loss caused by violation.9.2.3Party B shall observe policies of on-site management by the state and local gover nment authorities as well as Party A's rules and regulations; Party B shall compensate for the losses to any facilities, equipment or pipelines both inside and outside of the co nstruction yard caused by party B.9.2.4.During construction, Party B should make such adjustment to the construction pl an and the progress schedule per Party A's instruction and change-orders.9.2.5. Party B should transfer the construction site within days after the qualified completion.10.Agreement on SafetyParty B must strictly adhere to the Safety and Technical Standards of Construction an d Infrastructure Installation and regulation of China, Guangxi Zhuang Autonomous Region, Nanning Safety Standards and other relevant regulations and standards.the construction spot should meet all standards of the People's Republic of China. And bearing the safety fees which are not caused by party A.11.The concerning material supply11.1. Party A or Party B should be responsible for the material ,equipments,which should meet the qualified design request with qualification guarantee books.11.2. Any material,equipment which is bought by the Party B, if not agree with the quality request or specification contain difference,should forbid any usage.the Party B should rebuy the equipment and bear the responsibility to make sure no delay on the project.if Party B refuses to change the materials, Party A has the right to terminate the contract and asks for loss from Party B.11.3 Any material,equipment which is bought by the Party A, if not agree with the quality request or specification contain difference,should forbid any usage.the Party A should rebuy the equipment and bear the responsibility to make sure no delay on the project.12.Warranty12.1.Warranty scope: as state in the contract.12.2.Warranty period: 1 year after the qualified completion.12.3During the warranty period, Party B shall fix within 2 days after receiving the notice from Party A. In the event of Party B fails to fix the defects on a timely manner, Party A has the right to hire a third Party to do the repair, and any costs incurred shall be burdened by Party B.12.4. Mode of notices: phone, fax, e-mail, and so on.12.4.1 in the way of call the phone or faxing: Party B ’s TEL:,Fax: . These contact ways will be regarded as the evidence of warranty notice to Party B after the calling and faxing.12.4.2.in the way of posting: Party B ’s address:. These contact ways will be regarded as the evidence of warranty notice to Party B after e-mailing.12.4.3. in the way of e-mailing: Party B ’s e-mail: . These contact ways will be regarded as the evidence of warranty notice to Party B after e-mailing.12.4.4. The fees of noticing Party B will be borne by Party B.12.5. Project quality retention fee(tip: the blue words will be suite for under the condition of withing the Project quality retention fee)12.5.1Project quality retention fee: , which will be deduce from the project funds of Party B.12.5.2 After the expire date, Party A will return the rest of the quality retention fees without interest to Party B. This will be applied by Party B within ten days after the completion of qualified project.13. Liabilities for Breach13.1.In the event of Party A fails to make payment according to the payment terms, Party A should pay a late fee to Party B; Daily rate of the late fee is % of the payment. If the delay of the payment is caused by Party A and is delayed for more tha n days, then Party B can terminate this contract.13.2In the event of Party B fails to complete the project according to the construction period in the contract, Party B shall pay % of the t otal contract amount for each day overdue as penalty for the breach. Daily rate of the l ate fee is % of the payment.13.3.Party A can terminate this contract and Party B shall take full responsibility for a ny loss caused by this when one of these condition takes place.13.3.1 Overdue over days.13.3.2Party B transfers the contract and any part of the contract and its corresponding to any third party without Party A's consent in writing.13.3.3.Be ordered to shut down by the administrative organ caused by Party B over days.13.3.4.Safety and quality accidents.13.3.5. The materials provided by Party B differs from the QAcertificate and the Report of Quality Assurance Test. And Party B can not make change on these material.13.4.Party B should make salary/wages payment to all construction staffs in time on a monthly basis, and will be fully responsible for any liabilities caused by any loss or da mage to Party A as a result of Party B's failure to pay salaries and wages according to the requirements. In the event of migrant workers create a disturbance on group site, Party A's premises, office space, Party B should paid penal sum Yuan each time.13.5.In the event anyParty shall fail to complete the work in time owing to reasons that the contractor shall be held liable， the Party shall pay a penalty for RMB Yuan, and bear all be loss of the other Party.13.6. penal sums and other penalty fees that Party B should to Party A , Party A can take out the same amount of money directly from the project fees. (including quality retention fee).14.Other provisions14.1 Party A and Par ty B will deal with each party’s property and life insurance and assume their insurance costs respectively.14.2.Both Parties shall timely discuss each other for the settlement of any disputearising during the execution of this Contract. In case that such discussion fails, any Party can appeal to local people's court.14.3.Supplementary agreement could be made between the two parties in case that any additional clause shall be added. The supplementary agreement shall have the same effect and power as this Contract.14.4.This Contract shall come into force beginning from the date when both parties have stamped it with official Seal (or special stamp for contract) and signed it.14.5This contract will be printed and signed in 4 copies and Party A shall hold 3 copies. Party B shall hold 1 copies. And all have the same power and effect.15.Attachments:Party A: Party B:Legal Representative: Legal Representative:Address: Accounting Bank:Tel: Bank Account No.:Date: 2023-07-28 Address:Tel:Date: 2023-07-28。