FIDIC-条款-中英文对照版
- 格式:pdf
- 大小:829.68 KB
- 文档页数:107
fidic合同条款黄皮书中英文FIDIC合同条款1999(中英文对照)FIDIC合同条款1999(中英文对照)Fédération Internationale Des Ingénieurs-Conseils通用条件General Conditions1.一般规定1.1 定义在包括专用条件和本通用条件的合同条件(“本合同条件”)中,以下措辞和用语的含义如下所述。
除非上下文中另有要求,指当事人和当事各方的词包括公司和其它法律实体。
1.1.1 合同1.1.1.1“合同(Contract)”指合同协议书、中标函、投标函、本合同条件、规范、图纸、资料表、以及在合同协议书或中标函中列明的其它进一步的文件(如有时)。
1.1.1.2“合同协议书(Contract Agreement)”指第1.6款【合同协议】中所说明的合同协议(如有时)。
1.1.1.3“中标函(Letter of Acceptance)”指雇主对投标文件签署的正式接受函,包括其后所附的备忘录(由合同各方达成并签定的协议构成)。
在没有此中标函的情况下,“中标函”一词就指合同协议书,颁发或接收中标函的日期就指双方签订合同协议书的日期。
1.1.1.4“投标函(Letter of Tender)”指名称为投标函的文件,由承包商填写,包括已签字的对雇主的工程报价。
1.1.1.5“规范(Specification)”指合同中名称为规范的文件,及根据合同规定对规范的增加和修改。
此文件具体描述了工程。
1.1.1.6“图纸(Drawings)”指合同中规定的工程图纸,及由雇主(或代表)根据合同颁发的对图纸的增加和修改。
1.1.1.7“资料表(Schedules)”指合同中名称为资料表的文件,由承包商填写并随投标函提交。
此文件可能包括工程量表、数据、列表、及费率和/或单价表。
1.1.1.8“投标文件(Tender)”指投标函和合同中规定的承包商应随投标函提交的其它所有文件。
投标函附录(Appendix to Tender)转让(Assignment) 进场道路(Access Route)中标合同金额(Accepted Contract Amount)避免干扰(Avoidance of Interference)预付款(Advance Payment) 仲裁(Arbitration)申请期中支付证书(Application for Interim Payment Certificate) 竣工文件(“as built” documents)工程量清单(Bill of Quantities) 基准日期(Base Date)合同(Contract) 合同协议书(Contract Agreement)竣工(Completion) 合同价格(Contract Price)费用(Cost) 开工日期(Commencement Date)承包商的设备(Contractor’s Equipment) 合作(Co-operation) 承包商代表(Contractor’s Representative)承包商的文件(Contractor’s Documents)通信联络(Communications) 承包商(Contractor)承包商的一般义务(Contractor’s General Obligations )承包商人员(Contractor’s Personnel)承包商的现场作业(Contractor’s Operations on Site )开工(Commencement of Works) )雇主责任的终止(Cessation of Employer’s Liability )支付货币(Currencies of Payment) 工程所在国(Country)分包合同(Construction Subcontract)承包商的索赔(Contractor’s Claims)索赔、争端与仲裁(Claim, Disputes and Arbitration)图纸(Drawings) 缺陷通知期(Defects Notification)日期(Dates) 结清证明(Discharge)决定(Determinations) 误期损害赔偿费(Delay Damages)缺陷责任(Defects Liability) 计日工作(Daywork)延误的付款(Delayed Payment) 争议裁决委员会(DAB)业主(Employer) 业主的风险(Employer’s Risks)雇主人员(Employer’s Personnel) 估价(Evaluation)雇主的资金安排(Employer’s Financial Arrangements)雇主的索赔(Employer’s Claims) 工程师(Engineer)业主的设备(Employer’s Equipment)电、水和燃气(Electricity, Water and Gas)竣工时间的延长(Extension of Time)业主的接收(Employer’s Taking Over)最终报表(Final Statement) 不可抗力(Force Majeure)最终付款证书(Final Payment Certificate)外币(Foreign Currency) 化石(Fossils)货物(Goods)工程师指令(Instructions of the Engineers) 解释(Interpretation) 期中支付证书(Interim Payment Certificate) 检验(Inspection) 最终支付证书的签发(Issue of Final Payment Certificate)保险(Insurance) 投保人(insurance applicant)保险单(insurance policy)被保险人(insured)联合被保险人(joint insured)中标函(Letter of Acceptance)投标函(Letter of Tender) 责任限度(Limit of Liability) 当地币(Local Currency) 法律(Laws)计量方法(Method of Measurement)实施方法(Manner of Execution)材料(Materials)指定分包商(Nominated Subcontractor)遗留工作(Outstanding Work)合同当事人(Party) 文件优先次序(Priority of Documents)履约证书(Performance Certificate)支付证书(Payment Certificate) 生产设备(Plant)暂定金额(Provisional Sum) 付款(Payment)进度计划(Programme)永久工程(Permanent Works) 履约担保(Performance Security) 环境保护(Protection of the Environment)许可证,执照或批准(Permits, Licenses or Approvals)保留金的支付(Payment of Retention Money)暂列金额(Provisional Sums) 进度报告(Progress Reports)质量保证(Quality Assurance)保留金(Retention Money) 工程进度(Rate of Progress)现场进入权(Right of Access to the Site) 拒收(Rejection)修补工作(Remedial Work)复工(Resumption of Work)工程师的更换(Replacement of the Engineer)有权变更(Right to Vary)风险与责任(Risks and Responsibility)支付计划表(Schedule of Payments) 样品(Samples)资料表(Schedules) 规范(Specification)竣工报表(Statement at Completion)报表(Statement) 单位工程(Section)分包商(Subcontractor) 现场(Site)放线(Setting Out) 安全措施(Safety Procedures)现场数据(Site Data) 暂时停工(Suspension of Work)现场安保(Security of Site) 职员与劳工(Staff and Labour)投标书(Tender ) 试验(Testing)竣工时间(Time for Completion)竣工试验(Tests on Completion)接收证书(Taking-over Certificate)竣工后试验(Tests after Completion)临时工程(Temporary Works)竣工检验(Tests on Completion)货物运输(Transport of Goods)工程和单位工程的接收(Taking Over of the Works and Sections) 业主提出终止(Termination by Employer )发包商提出终止(Termination by Employer)不可预见(Unforeseeable) 变更(Variation)不可预见的物质条件(Unforeseeable Physical Conditions)变更与调整(Variation and Adjustment)价值工程(Value Engineering)变更程序(Variation Procedure)工程(Works) 工程计量(Works to be Measured)。
FIDIC国际土木建筑工程承包合同(英汉对照)(一) PART I —GENERAL CONDITIONS of CONTRACT 第一部分-合同条款概述Definitions and Interpretation定义和解释1。
1 Definitions定义 In the Contract (ashereinafter defined) the following words and expression_rs shall have the meanings hereby assigned to them, except where the context otherwise requires :本合同(按下文所定义的)中的下列词和用语,除文中另有要求者外,应具有本条所赋予的含义: a. (i)"Employer” means PHU MY HUNG CORPORATION, a company incorporated and registered at Saigon Parking Way Dist.7 HCMC. Vietnam。
“雇主"是PHU MY HUNG CORPORATION公司在Saigon Parking Way Dist。
7 HCMC。
Vietnam注册登记。
(ii)”Contractor" means the person named as such in Part II of these Conditions and the legal successors in title to such person, but not ( except with the consent of the Employer) any assignee of such person。
承包商是指第二部分指定的当事人以及取得此当事人资格的合法继承人,(除非雇主同意)不指此当事人的任何受让人。
1.1 测量方法12.2 Method of Measurement除非合同中另有规定,无论当地惯例如何:Except as otherwise stated in the Contract and notwithstanding local practice:(a) 测量应该是测量每部分永久工程的实际净值,以及(a) measurement shall be made of the net actual quantity of each item of the Permanent Works, and(b) 测量方法应符合工程量表或其他适用报表。
(b) the method of measurement shall be in accordance with the Bill of Quantities or other applicable Schedules.1.2 估价12.3 Evaluation除非合同中另有规定,工程师应通过对每一项工作的估价,根据第3.5款【决定】,商定或决定合同价格。
每项工作的估价是用依据上述第12.1款和第12.2款商定或决定的测量数据乘以此项工作的相应价格费率或价格得到的。
Except as otherwise stated in the Contract, the Engineer shall proceed in accordance with Sub-Clause 3.5 [Determinations] to agree or determine the Contract Price by evaluating each item of work, applying the measurement agreed or determined in accordance with the above Sub-Clauses 12.1 and 12.2 and the appropriate rate or price for the item.对每一项工作,该项合适的费率或价格应该是合同中对此项工作规定的费率或价格,或者如果没有该项,则为对其类似工作所规定的费率或价格。
FIDIC合同条款1999(中英文对照)Fédération Internationale Des Ingénieurs-Conseils通用条件General Conditions1.一般规定1.1 定义在包括专用条件和本通用条件的合同条件(“本合同条件”)中,以下措辞和用语的含义如下所述。
除非上下文中另有要求,指当事人和当事各方的词包括公司和其它法律实体。
1.1.1 合同1.1.1.1“合同(Contract)”指合同协议书、中标函、投标函、本合同条件、规范、图纸、资料表、以及在合同协议书或中标函中列明的其它进一步的文件(如有时)。
1.1.1.2“合同协议书(Contract Agreement)”指第1.6款【合同协议】中所说明的合同协议(如有时)。
1.1.1.3“中标函(Letter of Acceptance)”指雇主对投标文件签署的正式接受函,包括其后所附的备忘录(由合同各方达成并签定的协议构成)。
在没有此中标函的情况下,“中标函”一词就指合同协议书,颁发或接收中标函的日期就指双方签订合同协议书的日期。
1.1.1.4“投标函(Letter of Tender)”指名称为投标函的文件,由承包商填写,包括已签字的对雇主的工程报价。
1.1.1.5“规范(Specification)”指合同中名称为规范的文件,及根据合同规定对规范的增加和修改。
此文件具体描述了工程。
1.1.1.6“图纸(Drawings)”指合同中规定的工程图纸,及由雇主(或代表)根据合同颁发的对图纸的增加和修改。
1.1.1.7“资料表(Schedules)”指合同中名称为资料表的文件,由承包商填写并随投标函提交。
此文件可能包括工程量表、数据、列表、及费率和/或单价表。
1.1.1.8“投标文件(Tender)”指投标函和合同中规定的承包商应随投标函提交的其它所有文件。
1.1.1.9“投标函附录(Appendix to Tender)”指名称为投标函附录并已填写完毕的文件,附于投标函之后并构成投标函的一部分。
1.General Provisions一般规定Contract 合同Contract Agreement 合同协议书1。
6Letter of Acceptance 中标函1。
1。
3 (a. 业主对承包商正式接受函,签字;b.双方商定的其他内容,双方签字)Letter of Tender 投标函(承包商的报价函)Specification 规范Drawings 图纸Schedules 明细表Tender 投标书(a。
投标函;b。
投标者填写的各类明细表,投标保函等)Appendix to Tender 投标函附录Bill of Quantities 工程量表Daywork Schedule 计日工表Parties and Persons 合同双方和人员Engineer 工程师(natural/legal)(监理)DAB 争端裁决委员会(投标函附录列出)FIDIC 国际咨询工程联合会(International Federation of Consulting Engineers)Dates 日期Tests 检验Periods 期间Completion 竣工Base Date 基准日期(提交投标书截止日期之前的第28天当天;与调价有关) Commencement Date 开工日期(工程师通知开工的日期)Time for Completion 竣工日期(指时间段,从开工日期开始计算)Tests on Completion 竣工检验Taking—over Certificate 接收证书(证明工程按照合同实质竣工,进入缺陷通知期)Tests after Completion 竣工后检验Defects Notification Period 缺陷通知期维修期Performance Certificate 履约证书Money and Payments 款项和支付Accepted Contract Amount 中标合同金额(中标的承包商的投标价格,名义合同价格)Contract Prise 合同价格(a. b。
Fédération Internationale Des Ingénieurs-Conseils1.1 测量方法12.2 Method of Measurement除非合同中另有规定,无论当地惯例如何:Except as otherwise stated in the Contract and notwithstanding local practice:(a) 测量应该是测量每部分永久工程的实际净值,以及(a) measurement shall be made of the net actual quantity of each item of the Permanent Works, and(b) 测量方法应符合工程量表或其他适用报表。
(b) the method of measurement shall be in accordance with the Bill of Quantities or other applicable Schedules.1.2 估价12.3 Evaluation除非合同中另有规定,工程师应通过对每一项工作的估价,根据第3.5款【决定】,商定或决定合同价格。
每项工作的估价是用依据上述第12.1款和第12.2款商定或决定的测量数据乘以此项工作的相应价格费率或价格得到的。
Except as otherwise stated in the Contract, the Engineer shall proceed in accordance with Sub-Clause 3.5 [Determinations] to agree ordetermine the Contract Price by evaluating each item of work, applyingthe measurement agreed or determined in accordance with the above Sub-Clauses 12.1 and 12.2 and the appropriate rate or price for the item.对每一项工作,该项合适的费率或价格应该是合同中对此项工作规定的费率或价格,或者如果没有该项,则为对其类似工作所规定的费率或价格。
Fédération Internationale Des Ingénieurs-Conseils1.1 测量方法12.2 Method of Measurement除非合同中另有规定,无论当地惯例如何:Except as otherwise stated in the Contract and notwithstanding local practice:(a) 测量应该是测量每部分永久工程的实际净值,以及(a) measurement shall be made of the net actual quantity of each item of the Permanent Works, and(b) 测量方法应符合工程量表或其他适用报表。
(b) the method of measurement shall be in accordance with the Bill of Quantities or other applicable Schedules.1.2 估价12.3 Evaluation除非合同中另有规定,工程师应通过对每一项工作的估价,根据第3.5款【决定】,商定或决定合同价格。
每项工作的估价是用依据上述第12.1款和第12.2款商定或决定的测量数据乘以此项工作的相应价格费率或价格得到的。
Except as otherwise stated in the Contract, the Engineer shall proceed in accordance with Sub-Clause 3.5 [Determinations] to agree ordetermine the Contract Price by evaluating each item of work, applyingthe measurement agreed or determined in accordance with the above Sub-Clauses 12.1 and 12.2 and the appropriate rate or price for the item.对每一项工作,该项合适的费率或价格应该是合同中对此项工作规定的费率或价格,或者如果没有该项,则为对其类似工作所规定的费率或价格。
FOREWORD前言 (补充译文)The terms of the Fourth Edition of the Conditions of Contract for Works of Civil Engineering Construction have been prepared by the Fédération Internationale des Ingénieurs Conseils (FIDIC) and are recommended for general use for the purpose of construction of such works where tenders are invited on an intemational basis. The Conditions, subject to minor modifications, are also suitable for use on domestic contracts.土木工程施工合同条件的第四版已由国际咨询工程师联合会(以下简称为FIDIC)起草完成,并被推荐为以国际性招标为主的同类工程施工的通用条件,如果稍加修改,也适用于国内的招标合同。
The version in English of the Conditions is considered by FIDIC as the official and authentic text for the purpose of translation.本条件的英文版本, FIDIC已将其作为正式的和有效的语言文本,以用于翻译之目的。
In the preparation of the Conditions it was recognised that while there are numerous Clauses which will be generally applicable there are some Clauses which must necessarily vary to take account of the circumstances and locality of the Works. The Clauses of general application have been grouped together in this document and are referred to as Part I - General Conditions. They have been printed in a form which will facilitate their inclusion as printed in the contract documents normally prepared.在对本条件准备的过程中,发现多数条款是可以通用的,同时还考虑到工程所处的不同环境和地区须对某些条款加以必要的改动。
CONTENTS目录1 General Provisions 一般规定 (9)1.1 Definitions 定义 (9)1.2 Interpretation 解释 (21)1.3 Communications 通信交流 (22)1.4 Law and Language 法律和语言 (24)1.5 Priority of Document 文件优先次序 (24)1.6 Contract Agreement 合同协议书 (25)1.7 Assignment 权益转让 (26)1.8 Care and Supply of Document 文件的照管和提供 (26)1.9 Confidentiality 保密性 (27)1.10 Employer’s Use of Contractor’s Documents雇主使用承包商文件 (28)1.11 Contractor’s Use of Employer’s Documents承包商使用雇主文件 (30)1.12 Confidential Details 保密事项 (30)1.13 Compliance with Laws 遵守法律 (31)1.14 Joint and Several Liability 共同的和各自的责任 (32)2 The Employer 雇主 (33)2.1 Right of Access to the Site 现场进入权 (33)2.2 Permits, Licences or Approves 许可、执照或批准 (35)2.3 Employer’s personnel雇主人员 (36)2.4 Employer’s Financial Arrangements雇主的资金安排 (37)2.5 Employer’s Claims雇主的索赔 (37)3 The Employer’s Administration雇主的管理 (39)3.1 The Employer’s Representative雇主代表 (39)3.2 The Employer’s personnel其他雇主人员 (40)3.3 Delegated Persons 受托人员 (41)3.4 Instructions 指示 (43)3.5 Determinations 确定 (43)4 The Contractor 承包商 (44)4.1 The Contractor’s General Obligations承包商的一般义务 (45)4.2 Performance security 履约担保 (46)4.3 Contractor’s Representative承包商代表 (49)4.4 Subcontractors 分包商 (51)4.5 Nominated Subcontractors 指定的分包商 (52)4.6 Co-operation 合作 (52)4.7 Setting out 放线 (54)4.8 Safety procedures 安全程序 (55)4.9 Quality Assurance 质量保证 (56)4.10 Site Data 现场数据 (57)4.11 Sufficiency of the Contract Price 合同价格 (57)4.12 Unforeseeable Difficulties 不可预见的困难 (58)4.13 Rights of way and Facilities 道路通行权于设施 (59)4.14 Avoidance of Interference 避免干扰 (59)4.15 Access Route 进场通路 (60)4.16 Transport of Goods 货物运输 (62)4.17 Contractor’s Equipment承包商设备 (63)4.18 Protection of the Environment 环境保护 (63)4.19 Electricity, Water and Gas 电、水和燃气 (64)4.20 Employer’s Equipment and Free-Issue Material 雇主设备和免费供应的材料 (65)4.21 Progress Reports 进度报告 (67)4.22 Security of the Site 现场保安 (69)4.23 Contractor’s Operations on Site承包商的现场作业 (70)4.24 Fossils 化石 (71)5 Design 设计 (73)5.1 General Design Obligations 设计义务一般要求 (73)5.2 Contractor’s Documents承包商文件 (75)5.3 Contractor’s Undertaking承包商的承诺 (78)5.4 Technical Standards and Regulations 技术标准和法规 (78)5.5 Training 培训 (80)5.6 As-Built Documents 竣工文件 (80)5.7 Operation and Maintenance Manuals 操作和维修手册 (82)5.8 Design Error 设计错误 (82)6 Staff and Labour 员工 (83)6.1 Engagement of Staff and Labour 员工的雇用 (83)6.2 Rates of Wages and Conditions of Labour 工资标准和劳动条件 (83)6.3 Persons in the Service of Employer 为雇主服务的人员 (84)6.4 Labour Laws 劳动法 (84)6.5 Working Hours 工作时间 (85)6.6 Facilities for Staff and Labour 为员工提供设施 (85)6.7 Health and Safety 健康和安全 (86)6.8 Contractor’s Superintendence承包商的监督 (87)6.9 Contract or’s Personnel承包商人员 (88)6.10 Records of contractor’s Personnel and Equipment承包商人员和设备的记录 (89)6.11 Disorderly Conduct 无序行为 (90)7 Plant, Materials and Workmanship 生产设备、材料和工艺 (90)7.1 Manner of Execution 实施方法 (90)7.2 Samples 样品 (91)7.3 Inspection 检验 (92)7.4 Testing 试验 (93)7.5 Rejection 拒收 (96)7.6 Remedial Work 修补工作 (97)7.7 Ownership of Plant and Materials 生产设备和材料的所有权 (98)7.8 Royalties 土地(矿区)使用费 (99)8 Commencement,Delays and Suspension 开工、延误和暂停 (99)8.1 Commencement of Works 工程的开工 (99)8.2 Time for Completion 竣工时间 (100)8.3 Programme 进度计划 (101)8.4 Extension of Time for Completion 竣工时间延长 (103)8.5 Delays Caused by Authorities 当局造成的延误 (105)8.6 Rate of Progress 工程进度 (106)8.7 Delay Damages 误期损害赔偿费 (107)8.8 Suspension of Work 暂时停工 (108)8.9 Consequences of Suspension 暂停的后果 (109)8.10 Payment for Plant and Materials in Event of Suspension 暂停时对生产设备和材料的付款 (110)8.11 Prolonged Suspension 托长的暂停 (111)8.12 Resumption of Work 复工 (111)9 Tests on Completion 竣工试验 (112)9.1 Contractor’s Obligations承包商的义务 (112)9.2 Delayed Tests 延误的试验 (115)9.3 Retesting 重新试验 (116)9.4 Failure to Pass Tests on Completion 未能通过竣工试验 (116)10 Employer’s Taking Over雇主的接收 (118)10.1 Taking Over of the Works and Sections 工程和分项工程的接收.. 11810.2 Taking Over of Parts of the Works 部分工程的接收 (120)10.3 Interference with Tests on Completion 对竣工试验的干扰 (120)11 Defects Liability 缺陷责任 (121)11.1 Completion of Outstanding Work and Remedying Defects 完成扫尾工作和修补缺陷 (121)11.2 Cost of Remedying Defects 修补缺陷的费用 (122)11.3 Extension of Defects Notification Period 缺陷通知期的延长 (124)11.4 Failure to Remedy Defects 未能修补的缺陷 (125)11.5 Removal of Defective Work 移出有缺陷的工程 (126)11.6 Further Tests 进一步试验 (127)11.7 Right of Access 进入权 (128)11.8 Contractor to Search 承包商调查 (128)11.9 Performance Certificate 履约证书 (129)11.10 Unfulfilled Obligations 未履行的义务 (130)11.11 Clearance of Site 现场清理 (130)12 Tests after Completion 竣工后试验 (131)12.1 Procedure for Tests after Completion 竣工后试验的程序 (131)12.2 Delayed Tests 延误的试验 (133)12.3 Retesting 重新试验 (134)12.4 Failure to Pass Tests after Completion 未能通过的竣工后试验 (135)13 Variations and Adjustments 变更和调整 (137)13.1 Right to Vary 变更权 (137)13.2 Value Engineering 价值工程 (138)13.3 Variation Procedure 变更程序 (139)13.4 Payment in Applicable Currencies 以适用货币支付 (140)13.5 Provisional Sums 暂列金额 (141)13.6 Daywork 计日工作 (143)13.7 Adjustments for Changes in Legislation 因法律改变的调整 (144)13.8 Adjustments for Changes in Cost 因成本改变的调整 (146)14 Contract price and Payment 合同价格和支付 (146)14.1 The Contract Price 合同价格 (146)14.2 Advance payment 预付款 (147)14.3 Application for Interim Payments 期中付款的申请 (150)14.4 Schedule of Payments 付款价格表 (152)14.5 Plant and Materials intended for the Works 拟用于工程的生产设备和材料 (153)14.6 Interim Payments 期中付款 (154)14.7 Timing of Payments 付款的时间安排 (156)14.8 Delayed Payment 延误的付款 (157)14.9 Payment of Retention Money 保留金支付 (158)14.10 Statement at Completion 施工报表 (159)14.11 Application for Final Payment 最终付款的申请 (160)14.12 Discharge 结清证明 (162)14.13 Final Payment 最终付款 (163)14.14 Cessation of Employer’s Liability雇主责任的中止 (163)14.15 Currencies of Payment 支付的货币 (164)15 Termination by Employer 由雇主终止 (166)15.1 Notice to Correct 通知改正 (166)15.2 Termination by Employer 由雇主终止 (167)15.3 Valuation at Date of Termination 终止日期时的估价 (171)15.4 Payment after Termination 终止后的付款 (171)15.5 Employer’s Entitlement to Termination雇主终止的权利 (172)16 Suspension and termination by Contractor由承包商暂停和终止 (173)16.1 Contractor’s Entitlement to Suspend Work承包商暂停工作的权利 (173)16.2 Termination by Contractor 由承包商终止 (175)16.3 Cessation of Work and Removal of Contractor’s Equipment停止工作和承包商设备的撤离 (177)16.4 Payment on Termination 终止时的付款 (178)17 Risk and Responsibility 风险和职责 (179)17.1 Indemnities 保障 (179)17.2 Contractor’s Care of the Works承包商对工程的照管 (181)17.3 Employer’s Risks雇主的风险 (183)17.4 Consequence of Employer’s Risks雇主风险的后果 (184)17.5 Intellectual and Industrial Property Rights 知识产权和工业产权 18517.6 Limitation of Liability 责任限度 (187)18 Insurance 保险 (189)18.1 General Requirements for Insurances 有关保险的一般要求 (189)18.2 Insurance for Works and Contractor’s Equipment工程和承包商设备的保险 (193)18.3 Insurance against Injury to Persons and Damage to Property 人身伤害和财产损害险 (197)18.4 Insurance for Contractor’s Personnel承包商人员的保险 (199)19 Force Majeure 不可抗力 (200)19.1 Definition of Force Majeure 不可抗力的定义 (201)19.2 Notice of Force Majeure 不可抗力的通知 (203)19.3 Duty to Minimise Delay 将延误减至最小的义务 (204)19.4 Consequences of Force Majeure 不可抗力的后果 (204)19.5 Force Majeure Affecting Subcontractor 不可抗力影响分包商 (205)19.6 Optional Termination, Payment and Release 自主选择终止、支付和解除 (206)19.7 Release from Performance under the Law 根据法律解除履约 (208)20 Claims, Disputes and Arbitration 索赔、争端和仲裁 (209)20.1 Contra ctor’s Claims承包商的索赔 (209)20.2 Appointment of the Dispute Adjudication Board 争端裁决委员会的任命 (213)20.3 Failure to Agreement Dispute Adjudication Board 对争端裁决委员会未能取得一致时 (216)20.4 Obtaining Dispute Adjudication Board’s Decision取得争端裁决委员会的决定 (217)20.5 Amicable Settlement 友好解决 (221)20.6 Arbitration 仲裁 (221)20.7 Failure to Comply with Dispute Adjudication Board’s Decision未能遵守争端裁决委员会的决定 (223)20.8 Expiry of Dispute Adjudication Board’s Appointment争端裁决委员会任命期满 (224)1 General Provisions一般规定1.1 Definitions定义In the Conditions of Contract (“these Conditions”), which include Particular Conditions and these General Conditions, the following words and expressions shall have the meaning stated. Words indicating persons or parties include corporation and other legal entities, except where the context requires otherwise.在合同条件(“本条件”),包括专用条件和通用条件中,下列词语和措辞应具有以下所述的含义.除上下文另有要求外,文中人员或当事各方等词语包括公司和其他合法实体.1.1.1 The Contract合同1.1.1.1“Contract”means the Contract Agreement, these Conditions, the Employer’s Requirement, the Tender, and further document (if any) which are listed in the Contract Agreement.“合同”系指合同协议书、本条件、雇主要求、投标书和合同协议书列出的其他文件(如果有).1.1.1.2 “Contract Agreement”means the contract agreement referred to in Sub-Clause 1.6 [Contract Agreement], including any annexed memoranda.“合同协议书”系指第1.6款[合同协议书]中所述的合同协议书及所附各项备忘录.1.1.1.3“Employer’s requirements”means the document entitled employer’s requirements, as included in the Contract, and any additions and modifications to such document in accordance with the Contract. Such document specifies the purpose, scope, and/or design and/or other technical criteria, for the Works.“雇主要求”系指合同中包括的,题为雇主要求的文件,其中列明工程的目标、范围、和(或)设计和(或)其他技术标准,以及按合同对此项文件所作的任何补充和修改.1.1.1.4 “Tender”means the Contractor’s signed offer for the Works and all other documents which the Contractor submitted therewith (other than these Conditions and Employer’s Requirements, if so submitted), as included in the Contract.“投标书”系指包含在合同中的由承包商提交的为完成工程签署的报价,以及随同提交的所有其他文件(本条件和雇主要求除外,如同时提交).1.1.1.5“Performance Guarantees”and “Schedule ofpayments” mean the documents so named (if any), as included in the Contract.“履约保证”和“付款计划表”系指合同中包括的具有上述名称的文件(如果有).1.1.2 Parties and Persons各方和人员1.1.2.1 “Party” means the Employer or the Contractor, as thecontext requires.“当事方(或一方)”根据上下文需要,或指雇主,或指承包商。
Fédération Internationale Des Ingénieurs-Conseils通用条件General Conditions1.一般规定General Provisions1.1 定义Definitions在包括专用条件和本通用条件的合同条件(“本合同条件”)中,以下措辞和用语的含义如下所述。
除非上下文中另有要求,指当事人和当事各方的词包括公司和其它法律实体。
In the Conditions of Contract ("these Conditions"), which include Particular Conditions and these General Conditions, the following words and expressions shall have the meanings stated. Words indicating persons or parties include corporations and other legal entities, except where the context requires otherwise.1.1.1 合同1.1.1 The Contract1.1.1.1“合同(Contract)”指合同协议书、中标函、投标函、本合同条件、规范、图纸、资料表、以及在合同协议书或中标函中列明的其它进一步的文件(如有时)。
1.1.1.1 "Contract" means the Contract Agreement, the Letter of Acceptance, the Letter of Tender, these Conditions, the Specification, the Drawings, the Schedules, and the further documents (if any) which are listed in the Contract Agreement or in the Letter of Acceptance.1.1.1.2“合同协议书(Contract Agreement)”指第1.6款【合同协议】中所说明的合同协议(如有时)。
1.1.1.2 "Contract Agreement" means the contract agreement (if any) referred to in Sub-Clause 1.6 [Contract Agreement].1.1.1.3“中标函(Letter of Acceptance)”指雇主对投标文件签署的正式接受函,包括其后所附的备忘录(由合同各方达成并签定的协议构成)。
在没有此中标函的情况下,“中标函”一词就指合同协议书,颁发或接收中标函的日期就指双方签订合同协议书的日期。
1.1.1.3 "Letter of Acceptance" means the letter of formal acceptance, signed by the Employer, of the Letter of Tender, including any annexed memoranda comprising agreements between and signed by both Parties. If there is no such letter of acceptance, the expression "Letter of Acceptance" means the Contract Agreement and the date of issuing or receiving the Letter of Acceptance means the date of signing the Contract Agreement.1.1.1.4“投标函(Letter of Tender)”指名称为投标函的文件,由承包商填写,包括已签字的对雇主的工程报价。
1.1.1.4 "Letter of Tender" means the document entitled letter of tender, which was completed by the Contractor and includes the signed offer to the Employer for the Works.1.1.1.5“规范(Specification)”指合同中名称为规范的文件,及根据合同规定对规范的增加和修改。
此文件具体描述了工程。
1.1.1.5 "Specification" means the document entitled specification, as included in the Contract, and any additions and modifications to the specification in accordance with the Contract. Such document specifies the Works.1.1.1.6“图纸(Drawings)”指合同中规定的工程图纸,及由雇主(或代表)根据合同颁发的对图纸的增加和修改。
1.1.1.6 "Drawings" means the drawings of the Works, as included in the Contract, and any additional and modified drawings issued by (or on behalf of, the Employer in accordance with the Contract.1.1.1.7“资料表(Schedules)”指合同中名称为资料表的文件,由承包商填写并随投标函提交。
此文件可能包括工程量表、数据、列表、及费率和/或单价表。
1.1.1.7 "Schedules" means the document(s) entitled schedules, completed by the Contractor and submitted with the Letter of Tender, as included in the Contract. Such document may include the Bill of Quantities, data, lists, and schedules of rates and/or prices1.1.1.8“投标文件(Tender)”指投标函和合同中规定的承包商应随投标函提交的其它所有文件。
1.1.1.8 "Tender" means the Letter of Tender and all other documents which the Contractor submitted with the Letter of Tender, as included in the Contract.1.1.1.9“投标函附录(Appendix to Tender)”指名称为投标函附录并已填写完毕的文件,附于投标函之后并构成投标函的一部分。
1.1.1.9 "Appendix to Tender" means the completed pages entitled appendix to tender which are appended to and form part of the Letter of Tender.1.1.1.10 “工程量表(Bill of Quantities)”和“计日工计划(Daywork Schedule)”指资料表中如此命名的文件(如有时)。
1.1.1.10 "Bill of Quantities" and "Day work Schedule" mean the documents so named (if any) which are comprised in the Schedules.1.1.2 当事各方和当事人1.1.2Parties and Persons1.1.2.1“一方(Party)”指雇主或承包商(根据上下文而定)。
1.1.2.1 "Party" means the Employer or the Contractor, as the context requires.1.1.2.2“雇主(Employer)”指在投标函附录中指定为雇主的当事人或此当事人的合法继承人。
1.1.2.2 "Employer" means the person named as employer in the Appendix to Tender and the legal successors in title to this person.1.1.2.3“承包商(Contractor)”指在雇主收到的投标函中指明为承包商的当事人(一个或多个)及其合法继承人。
1.1.2.3 "Contractor" means the person(s) named as contractor in the Letter of Tender accepted by the Employer and the legal successors in title to this person(s).1.1.2.4“工程师(Engineer)”指雇主为合同之目的指定作为工程师工作并在投标函附录中指明的人员,或由雇主按照第3.4款【工程师的撤换】随时指定并通知承包商的其他人员。
1.1.2.4 "Engineer" means the person appointed by the Employer to act as the Engineer for the purposes of the Contract and named in the Appendix to Tender, or other person appointed from time to time by the Employer and noted to the Contractor under Sub-Clause3.4 [Replacement of the Engineer].1.1.2.5“承包商的代表(Contractor’s Representitive)”指承包商在合同中指定的或由承包商按照第4.3款【承包商的代表】随时指定的代表承包商的人员。