室内(办公室)设计装修合同-中英文

普通家庭装修合同【中英文版】Title: Ordinary Family Home Renovation Contract1.Parties involved:English: The contract is made between Mr.John Smith, the homeowner, and XYZ Construction Co., Ltd., the contractor.中文：本合同由业主约翰·史密斯先生与施工方xyz建筑有限公司签订。

2.Scope of work:English: The renovation work includes, but is not limited to, the refurbishment of the living room, kitchen, two bathrooms, and three bedrooms.中文：装修工作包括但不限于客厅、厨房、两个卫生间和三间卧室的翻新。

3.Timeframe:English: The renovation is expected to be completed within a period of six months from the start date, which is scheduled for March 1st, 2023.中文：装修预计将在起始日期，即2023年3月1日起的六个月内完成。

4.Payment terms:English: Payment will be made in three installments, with the first payment of 30% upon signing the contract, the second payment of 40% upon completion of the structural work, and the final payment of 30% upon final inspection and approval by the homeowner.中文：支付将分三次进行，签约时支付30%的首付款，结构工程完成后支付40%的进度款，最终验收并得到业主批准后支付剩余的30%。

全面的室内装潢契约英文版Comprehensive Interior Decorating ContractWhen it comes to designing or renovating the interior of your home or office, having a detailed and comprehensive contract in place is essential to ensure that both parties are clear on the terms and expectations of the project. This document will outline all the necessary details such as the scope of work, timeline, budget, materials, and any other specific requirements that need to be agreed upon before the project begins.The interior decorating contract should include a detailed description of the work to be done, including the specific rooms or areas that will be decorated, the types of materials and finishes to be used, and any special requests or design preferences. It should also outline the responsibilities of both the client and the decorator, including payment terms, deadlines, and any additional services that may be provided.By having a comprehensive contract in place, both parties can avoid any potential misunderstandings or disputes that may arise during the course of the project. It provides a clear roadmap for the project, ensuring that everyone is on the same page and working towards a common goal.In conclusion, a comprehensive interior decorating contract is a crucial document that should not be overlooked. It serves as a legal and binding agreement between the client and the decorator, outlining all the necessary details to ensure a successful and smooth project completion. Make sure to carefully review and discuss the contract with your decorator before signing to ensure that all parties are in agreement and that the project can proceed as planned.。

装饰工程合同Con tract of Con structi onProject合同编号：Con tract Number:工程名称：Project Name:发包方(甲方)：Employer (Party A):承包方(乙方)：Con tractor (Party B):根据《中华人民共和国合同法》和《建筑安装工程承包合同条例》及有关规定，为明确双方在施工过程中的权利、义务和经济责任，经双方协商同意签订本合同。

In order to make definite of the rights, obligations and economic responsibilities ofboth parties duri ng the con structi on, the parties, in accorda nee with The PRC Con tract Law and Con structi on Engin eeri ng Con tract Regulati ons and releva nt provisi ons, agreeto sig n this con tract.第一条工程项目Article 1, Project item1 .工程地点：Project site:2. 工程范围：Scope of project3. 工程造价：人民币 ____________ 元整(该造价为包工包料价)Project cost: PMB Yua n only (Cost of this con tract is the con tract price for laborand materials)第二条施工准备Article 2, Preparati on for con structi on1 •甲方协助乙方办理临时水电及垂直运输，提供建筑图纸及有关隐蔽障碍物的资料。

Party A shall assists party B to deal with the procedures of temporary hydropower and vertical tra nsportatio n and provide architectural draw ings and docume nts of releva nt con cealed obstacles .2 .乙方：.Party B:①负责施工区域的临时设施、水电管线的铺设、管理、使用和维修工作；Be responsible for the works of laying, management, use and maintenance of the temporary facilities, water and electricity pipeli ne in the con structi on area.②组织施工管理人员和材料、施工机械进场；Orga nize con structi on man ageme nt staff and con structi on materials, con structi on machinery enter the Site.③负责在装修期间保持公共地方清洁及每天负责将装物料弃置于由管理处指定的垃圾收集处。

全篇的装修合同英文版Complete Renovation ContractThis document serves as a comprehensive agreement between the homeowner and the contractor for the renovation of the property located at [insert address]. The scope of work includes but is not limited to: demolition, construction, plumbing, electrical, painting, and finishing.1. Parties Involved- Homeowner: [Name]- Contractor: [Name]2. Scope of Work- Demolition of existing structures- Construction of new walls, floors, and ceilings- Plumbing work including installation of fixtures- Electrical work including wiring and outlets- Painting of walls and finishing touches3. Timeline- The renovation work is expected to be completed within [insert timeframe]. Delays due to unforeseen circumstances may extend the timeline.4. Payments- The total cost of the renovation is [insert amount]. Payments will be made in installments as follows:- [Insert payment schedule]5. Change Orders- Any changes to the scope of work must be agreed upon by both parties in writing. Additional costs incurred due to change orders will be discussed and approved before work begins.6. Permits and Inspections- The contractor is responsible for obtaining all necessary permits and ensuring that the work meets building codes and regulations. Inspections will be conducted at various stages of the renovation.7. Warranty- The contractor guarantees the quality of workmanship and materials used for a period of [insert timeframe]. Any defects or issues will be addressed and rectified by the contractor at no additional cost to the homeowner.8. Termination- Either party may terminate the contract with written notice if the other party fails to fulfill their obligations. Termination may result in financial penalties or legal action.9. Governing Law- This contract is governed by the laws of [insert jurisdiction]. Any disputes arising from the contract will be resolved through arbitration.10. Signatures- Both parties acknowledge that they have read and agreed to the terms of this contract by signing below:Homeowner: [Signature] Date: [Date]Contractor: [Signature] Date: [Date]。

办公室设计合同合同号：________________签订日期：________________签订地点：________________根据《中华人民共和国合同法》以及其他相关法律、法规，结合室内装饰的特点，经甲、乙双方友好协商，甲方委托乙方承担室内装饰设计，并达成如下协议。

一、甲方委托室内设计的地址________________________，房型____________，总面积____________平方米。

二、甲方委托乙方室内设计，且乙方不负责施工，其设计收费标准为每平方米____________美元，收取设计费共计____________美元。

甲方应在合同签署时付首期50% 设计费，并与乙方约定上门测量的时间和地点。

乙方设计师在测量后____天内完成平面布置图及顶面布置图。

三、乙方完成初步设计方案后，甲方与乙方设计师经过沟通同意，填写设计方案进程表。

甲方应支付设计费余款，乙方设计师将在____天内完成全套装潢设计图。

四、图纸完成后，甲方如有更改意见，再与乙方设计师沟通。

乙方根据协商方案，绘制更改图纸，双方再次填写设计方案进程表。

图纸更改确认后，乙方将全套图纸交给甲方使用。

五、施工过程中，乙方设计师应至少有三次去现场指导施工，以达到设计效果。

六、违约责任：1.乙方未在约定时间内完成设计图且延期时间在_____天内的，每延期一天应当支付设计费总价的 3% 违约金给甲方。

2. 乙方延期____天以上未完成设计图的，甲方有权解除合同，乙方应退还甲方的设计费用，并承担设计费总价 50% 的违约金。

3. 乙方无故终止合同，除退还甲方所交的设计费用外，还应按合同规定的设计费总价的 50% 作为违约金付给甲方。

七、设计合同经双方签字认可后，甲方必须按合同约定支付设计费。

如甲方中途取消合同，乙方不再退还已收取的设计费。

八、除本合同外，甲乙双方之间的所有往来函件，乙方给甲方的资料、图纸等均采用英文。

九、本合同中如有未尽事宜，由双方协商解决,协商不成，由甲方所在地人民法院裁决。

MEMORANDUM OF AGREEMENT BETWEEN CLIENT & DESIGN CONSULTANT MEMORANDUM OF AGREEMENT made this 29 May 2013 between A (hereinafter called "the Client" which expression includes their legal representatives, successors in title an assigns) of the one part and B practising as design consultant at C (hereinafter called “the Designer" which expression includes his/legal representatives, successors in titles and permitted assigns) of the other part.WHEREAS the Client intends to construct and complete. (hereinafter called 'the project');AND WHEREAS the Client is desirous of appointing the Designer to provideprofessional design services for the Project on the terms and conditions hereinafter appearingIT IS HEREBY AGREED BETWEEN THE PARTIES HERETO AS FOLLOWS:1.0 SCOPE OF WORK 服务范围1.1 Interior layout and spatial re-planning of all areas.室内布局和所有领域的空间重新规划。

英文装修合同范本三篇篇一Renovation ContractThis Renovation Contract ("Contract") is made and entered into on [date] between [Client's Name] ("Client") and [Contractor's Name] ("Contractor").1. Project DescriptionThe Contractor shall undertake the renovation project of the property located at [Property Address] ("Property") as described in the attached plans and specifications (collectively, the "Project").2. Project TimelineThe Contractor shall mence the Project on [Start Date] and plete it [Completion Date], subject to any extensions agreed upon in writing the Client and the Contractor.3. Project CostThe total cost of the Project is $[Total Cost] (inclusive of materials, labor, and all other expenses). The Client shall make the following payments to the Contractor:A deposit of $[Deposit Amount] upon signing this Contract.Progress payments as per the agreed milestones during the Project.The final payment of $[Final Payment Amount] upon satisfactory pletion and acceptance of the Project.4. Materials and WorkmanshipThe Contractor shall use materials of good quality and perform the work in a professional and workmanlike manner in accordance with industry standards.5. Changes and AmendmentsAny changes or amendments to the Project scope, specifications, or cost shall be agreed upon in writing both parties and signed as addendums to this Contract.6. Inspections and AcceptanceThe Client shall have the right to inspect the progress and pleted work. The Project shall be deemed accepted the Client upon written notification or if no notification of rejection is provided within [Acceptance Period] days after pletion.7. WarrantiesThe Contractor warrants that the work performed will be free from defects in materials and workmanship for a period of [Warranty Period] from the date of acceptance.8. TerminationThis Contract may be terminated either party in the event of a material breach of its terms. In such case, the breaching party shall be liable for any damages incurred.9. Dispute ResolutionAny disputes arising under this Contract shall be resolved through amicable negotiation. If negotiation fls, the matter shall be submitted to arbitration in accordance with the laws of [Jurisdiction].10. Governing LawThis Contract shall be governed and construed in accordance with the laws of [Jurisdiction].IN WITNESS WHEREOF, the parties have executed this Contract as of the date first above written.Client's Signature: [Client's Signature]Client's Name: [Client's Name]Client's Address: [Client's Address]Contact Number: [Client's Contact Number]Contractor's Signature: [Contractor's Signature]Contractor's Name: [Contractor's Name]Contractor's Address: [Contractor's Address]Contact Number: [Contractor's Contact Number]篇二Renovation ContractThis Renovation Contract ("Contract") is made and entered into on [date] and between [Client's Name] ("Client") and [Contractor's Name] ("Contractor").1. Project DescriptionThe Contractor shall undertake the renovation project at the property located at [Property Address] (the "Property"). The scope of work includes but is not limited to [list the specific renovation tasks, such as pnting, flooring, plumbing, etc.].2. Project TimelineThe renovation project is estimated to mence on [Start Date] and be pleted [Completion Date], subject to any unforeseen circumstances or delays as mutually agreed upon in writing.3. Project CostThe total cost of the renovation project is agreed to be $[Total Cost]. The Client shall make the following payments:A deposit of $[Deposit Amount] upon signing this Contract.Progress payments as follows: [Specify the payment schedule and amounts based on project milestones.]4. Materials and WorkmanshipThe Contractor shall use materials of good quality and perform the work in a professional and workmanship-like manner. All materials used shall conform to the specifications agreed upon both parties.5. Changes and AmendmentsAny changes or amendments to the scope of work, materials, or project timeline shall be mutually agreed upon in writing and may result in adjustments to the project cost and timeline.6. Inspection and AcceptanceUpon pletion of the project, the Client shall inspect the work. If the work is found to be in accordance with the agreed-upon specifications and satisfactory, the Client shall provide written acceptance.7. Warranties and GuaranteesThe Contractor warrants that the work performed shall be free from defects in materials and workmanship for a period of [Warranty Period] from the date of pletion.8. Dispute ResolutionIn the event of any dispute or disagreement arising out of or in connection with this Contract, the parties shall attempt to resolve the matter through amicable negotiation. If negotiation fls, the dispute shall be submitted to arbitration in accordance with the rules of [Arbitration Institution].9. TerminationThis Contract may be terminated either party in the event of a material breach of its terms and conditions the other party.10. Entire AgreementThis Contract constitutes the entire agreement between the parties and supersedes all prior negotiations, understandings, and agreements.IN WITNESS WHEREOF, the parties have executed this Contract as of the date first above written.Client's Signature: ____________________Client's Name: ____________________Client's Address: ____________________Client's Contact Number: ____________________Contractor's Signature: ____________________Contractor's Name: ____________________Contractor's Address: ____________________Contractor's Contact Number: ____________________篇三Renovation ContractThis Renovation Contract ("Contract") is made and entered into on [date] between [Client's Name] ("Client") and [Contractor's Name] ("Contractor").1. Project DescriptionThe Contractor agrees to undertake the renovation project described as follows: [Describe the scope and detls of the renovation work, including rooms, specific tasks, materials to be used, etc.]2. Project TimelineThe renovation work is expected to mence on [start date] and be pleted [pletion date]. The Contractor shall make every effort to meet the agreed-upon timeline.3. Project CostThe total cost of the renovation project is agreed to be $[total amount]. The Client shall make the following payments:A deposit of $[deposit amount] upon signing this contract.Progress payments as follows: [Specify the payment schedule and amounts based on project milestones.]4. Materials and WorkmanshipThe Contractor shall use materials of good quality and perform the work in a professional and workmanship-like manner. Any defects or issues arising from substandard materials or workmanship shall be rectified the Contractor at no additional cost to the Client within a reasonable time.5. Changes and AmendmentsAny changes or amendments to the project scope, design, or materials must be mutually agreed upon in writing both the Client and the Contractor. Such changes may result in adjustments to the project cost and timeline.6. Insurance and LiabilityThe Contractor shall carry appropriate insurance coverage for the duration of the project. The Contractor shall be liable for any damages or injuries caused during the course of the work, except for those caused the Client's actions or negligence.7. WarrantyThe Contractor provides a warranty for the renovation work for a period of [warranty period] from the date of pletion. During this period, the Contractor shall address any defects or issues arising from the work at no cost to the Client.8. TerminationEither party may terminate this contract under the following circumstances: Material breach of the contract the other party.Unforeseen circumstances that make it impossible to plete the project.In the event of termination, the rights and obligations of both parties shall be determined in accordance with the terms of this contract and applicable laws.9. Dispute ResolutionIn the event of a dispute arising from this contract, both parties shall attempt to resolve the matter through amicable negotiation. If negotiation fls, the dispute shall be submitted to arbitration or litigation in accordance with the laws of [jurisdiction].10. Entire AgreementThis Contract constitutes the entire agreement between the Client and the Contractor regarding the renovation project and supersedes all prior discussions and agreements.By signing below, both the Client and the Contractor agree to be bound the terms and conditions of this Contract.Client's Signature: [Client's Name] Date: [date]Contractor's Signature: [Contractor's Name] Date: [date]Please note that this is a basic template and should be customized and reviewed a legal professional to meet the specific requirements and laws of your jurisdiction.。

5个标准版室内装修设计合同英文版Title: 5 Standard Indoor Decoration Design ContractsWhen it comes to interior decoration design contracts, it is crucial to ensure that all parties involved are on the same page. Here are five essential elements that should be included in a standard indoor decoration design contract:1. Scope of Work: This section should clearly outline the specific tasks and responsibilities of both the designer and the client. It should detail the design services to be provided, the timeline for completion, and any additional services that may be required.2. Payment Terms: It is important to clearly define the payment terms in the contract. This should include the total cost of the design services, the payment schedule, and any additional fees that may apply. Both parties should agree on the payment terms before work begins.3. Design Approval Process: The contract should outline the process for design approval. This should include how designs will be presented to the client, how revisions will be handled, and the deadlines for design approval. Clear communication is key to ensuring a successful design process.4. Ownership of Design: This section should address the ownership rights of the design work. It should specify that the designer retains ownership of the design until full payment is received. Once payment is made, the client will have full rights to use the design as outlined in the contract.5. Termination Clause: In the event that either party wishes to terminate the contract, there should be a clear termination clause included. This should outline the steps that need to be taken to terminate the contract, any penalties or fees that may apply, and the process for resolving any disputes that may arise.By including these five elements in a standard indoor decoration design contract, both parties can ensure a smooth and successful designprocess. It is important to review the contract carefully and make any necessary revisions before signing to avoid any misunderstandings or disputes down the line.。

全面版房屋装修合同书英文版Comprehensive House Renovation ContractThis contract is entered into between the homeowner, referred to as the "Client," and the renovation contractor, referred to as the "Contractor," on [date].1. Scope of Work:The Contractor agrees to provide all labor, materials, and equipment necessary to complete the renovation of the Client's house located at [address]. This includes but is not limited to painting, flooring, plumbing, electrical work, and carpentry.2. Schedule:The renovation work is expected to begin on [start date] and be completed by [end date]. The Contractor shall provide a detailed schedule of work to the Client prior to the start date.3. Payment:The total cost of the renovation project is agreed upon as [total amount]. The Client agrees to make payments according to the following schedule:- 50% deposit due prior to the start of work- 25% payment due at the halfway point of the project- 25% final payment due upon completion of the project4. Changes and Extras:Any changes or additional work requested by the Client must be agreed upon in writing and may result in additional costs and extended completion time.5. Quality of Work:The Contractor agrees to perform all work in a professional and workmanlike manner, using materials of good quality and in accordance with industry standards.6. Warranty:The Contractor warrants all workmanship and materials for a period of [warranty period] from the date of completion. Any defects that arise during this period will be repaired by the Contractor at no additional cost to the Client.7. Termination:Either party may terminate this contract with written notice if the other party fails to fulfill their obligations. In the event of termination, the Client will pay for all work completed up to that point.8. Disputes:Any disputes arising from this contract will be resolved through mediation. If mediation is unsuccessful, the parties agree to arbitration in accordance with [arbitration rules].9. Governing Law:This contract shall be governed by the laws of [state/country] and any disputes shall be resolved in the courts of [jurisdiction].10. Signatures:Both parties acknowledge that they have read and understood the terms of this contract and agree to be bound by them.Client Signature: ________________________ Date:_______________Contractor Signature: _____________________ Date:_______________。

全面的房屋装修协议英文版Comprehensive Home Renovation AgreementIntroductionThis document serves as a legally binding agreement between the homeowner and the contractor for the renovation of the property located at [insert address]. This agreement outlines the scope of work, timelines, payment terms, and responsibilities of both parties involved in the renovation project.Scope of Work1. The contractor agrees to provide all labor, materials, and equipment necessary to complete the renovation project as outlined in the attached project plan.2. The homeowner agrees to provide access to the property and ensure that all necessary permits and approvals are obtained before the start of the renovation.Timelines1. The renovation project is expected to commence on [start date] and be completed by [end date].2. Any delays in the project timeline due to unforeseen circumstances will be communicated promptly by the contractor to the homeowner.Payment Terms1. The total cost of the renovation project is estimated at [total cost], broken down into installments as follows:- 25% deposit due upon signing of this agreement- 50% payment due upon completion of major milestones- 25% final payment upon completion of the renovation project2. Any additional work requested by the homeowner not includedin the original scope of work will be subject to additional charges.Responsibilities1. The contractor is responsible for ensuring that all work is completed in a timely manner and meets the quality standards outlinedin the project plan.2. The homeowner is responsible for providing clear instructions and feedback to the contractor throughout the renovation process.ConclusionBoth parties acknowledge and agree to the terms outlined in this comprehensive home renovation agreement. Any disputes arising from this agreement will be resolved through mediation or arbitration.Signed:Homeowner [signature]Contractor [signature]Date: [date]。

2024年家居装修合同样本英文版Sample Home Renovation Contract for 2024This document serves as a template for a home renovation contract for the year 2024. It outlines the terms and conditions between the homeowner and the contractor for the renovation project.Parties Involved1. Homeowner: [Name]2. Contractor: [Company Name]Scope of Work1. Description of Work: The contractor agrees to provide renovation services for the homeowner's property located at [Address].2. Timeline: The renovation project is expected to be completed by [Date].3. Materials: The contractor will provide all necessary materials for the renovation, unless otherwise specified.4. Payment: The total cost of the renovation is estimated to be [Amount]. Payment will be made in installments as outlined in the contract.Responsibilities1. Homeowner Responsibilities: The homeowner is responsible for providing access to the property and ensuring a safe working environment for the contractor.2. Contractor Responsibilities: The contractor is responsible for completing the renovation work in a timely and professional manner.Change OrdersAny changes to the scope of work must be agreed upon in writing by both parties. Additional costs resulting from change orders will be added to the total cost of the renovation.Dispute ResolutionIn the event of a dispute, both parties agree to first attempt to resolve the issue through mediation. If mediation is unsuccessful, the dispute will be resolved through arbitration.TerminationEither party may terminate the contract with written notice if the other party breaches the terms of the agreement. In such cases, the terminating party may be entitled to compensation or damages as outlined in the contract.Governing LawThis contract shall be governed by the laws of [State/Country]. Any legal disputes arising from this contract shall be resolved in the appropriate jurisdiction.This document is a basic template and may need to be customized to suit the specific needs of the homeowner and contractor. It is important to review all terms and conditions carefully before signing the contract.。

室内装修改造合同（中英文实用版）Title: Interior Renovation Contract1.Parties involved:Contractor: XYZ Construction Co., Ltd.Client: Mr.John Smith1.Scope of Work:The contractor shall be responsible for the following renovation works:- Remodeling of the living room, bedroom, and kitchen- Installation of new flooring, tiles, and paint- Installation of new electrical and plumbing systems- Installation of new kitchen cabinets and countertops1.Timeframe:The renovation works shall commence on March 1, 2022, and be completed by May 1, 2022.1.Payment Terms:The client shall pay the contractor a 50% deposit upon signing of the contract.The remaining 50% shall be paid upon completion of the renovation works.1.Dispute Resolution:Any disputes arising out of or in connection with this contract shallbe resolved by arbitration in accordance with the rules of the International Chamber of Commerce.erning Law:This contract shall be governed by and construed in accordance with the laws of the People"s Republic of China.2.Amendments:This contract may be amended or modified only by a written instrument executed by both parties.2.Entire Agreement:This contract constitutes the entire agreement between the parties and supersedes all prior agreements and understandings, whether written or oral, between the parties.甲方（业主）：约翰·史密斯先生乙方（施工方）：XYZ建筑有限公司1.工程范围：乙方应负责以下装修工作：- 客厅、卧室和厨房的改造- 铺设新地板、瓷砖和油漆- 安装新的电气和给排水系统- 安装新的厨房橱柜和台面1.工程期限：装修工程应自2022年3月1日起开始，至2022年5月1日完成。

5个室内设计装修合同通用样式英文版5 Common Styles of Interior Design and Renovation ContractsWhen entering into an agreement for interior design and renovation services, it is essential to have a clear and comprehensive contract in place. Here are five common styles of interior design and renovation contracts that you can consider:1. Fixed Price Contract: This type of contract outlines a set price for the entire project, providing clarity on the total cost of the services to be provided.2. Time and Materials Contract: In this contract, the client pays for the materials used and the time spent on the project. This allows for flexibility in case there are any changes or additions to the original plan.3. Cost-Plus Contract: With this contract, the client agrees to pay the contractor the actual cost of the materials and labor plus anadditional percentage as profit. This style provides transparency in the pricing structure.4. Design-Build Contract: In a design-build contract, the same company is responsible for both the design and construction of the project. This can streamline the process and ensure better communication between the design and construction teams.5. Turnkey Contract: A turnkey contract is where the contractor takes full responsibility for the entire project, from design to completion. This style is ideal for clients who want a hassle-free experience and prefer to leave the details to the professionals.Each of these contract styles has its own advantages and considerations, so it is important to carefully review and choose the one that best suits your needs and preferences before signing on the dotted line.。

Contract for Home RenovationThis Contract (the "Contract") is made and entered into as of [Date], by and between [Homeowner's Name], hereinafter referred to as the "Homeowner," and [Contractor's Name], hereinafter referred to as the "Contractor."1. Scope of WorkThe Contractor agrees to perform the following renovation services (the "Work") at the Homeowner's property located at [Property Address]:[List the specific renovation services to be performed, such as kitchen remodeling, bathroom renovation, painting, etc.]2. Term of ContractThe Contract shall commence on [Start Date] and shall continue until the completion of the Work, or until terminated in accordance with the terms of this Contract.3. Payment TermsThe Homeowner agrees to pay the Contractor the total contract price of [Total Contract Price] for the completion of the Work, as outlined in the attached Schedule A.A down payment of [Down Payment Amount] shall be paid by the Homeowner to the Contractor within [Number of Days] days after the execution of this Contract.The remaining balance of the total contract price shall be paid by the Homeowner to the Contractor upon completion of the Work, subject to the satisfaction of the Homeowner with the quality and completion of the Work.4. Timeline and Completion DateThe Contractor agrees to complete the Work within [Project Duration] from the commencement date, as outlined in the attached Schedule A.In the event that the Contractor fails to complete the Work within the agreed-upon timeframe, the Homeowner shall be entitled to a daily penalty equivalent to [Percentage of Total Contract Price] per day of delay, to be calculated from the original completion date until the actual completion date.5. Change OrdersAny changes to the scope of work, timeline, or payment terms shall be mutually agreed upon by both the Homeowner and the Contractor in writing.In the event of a change order, the Contractor shall provide the Homeowner with a revised schedule, budget, and any additional terms that may apply.6. Materials and QualityThe Contractor shall use quality materials and perform the Work in a professional, workmanlike manner, in accordance with industry standards and applicable building codes.The Contractor shall be responsible for obtaining all necessary permits and approvals from local authorities, at the Homeowner's expense, unless otherwise agreed upon in writing.7. Inspection and AcceptanceUpon completion of the Work, the Homeowner shall have the right to inspect the Work and request any necessary corrections or touch-ups.The Work shall be considered accepted by the Homeowner upon satisfaction with the quality and completion of the Work, or upon the expiration of [Number of Days] days after the completion date, whichever occurs first.8. WarrantyThe Contractor warrants that the Work shall be free from defects in materials and workmanship for a period of [Warranty Duration] from the date of completion.In the event of a covered defect, the Contractor shall repair or replace the defective materials or workmanship at the Contractor's sole expense.9. Dispute ResolutionAny disputes arising out of or in connection with this Contract shall be resolved by means of mediation, followed by binding arbitration, in accordance with the rules of the American Arbitration Association.10. Entire AgreementThis Contract constitutes the entire agreement between the Homeowner and the Contractor, superseding any prior agreements, whether written or oral.This Contract may be amended or modified only by a written instrument executed by both the Homeowner and the Contractor.11. Governing Law and JurisdictionThis Contract shall be governed by and construed in accordance with the laws of the state of [State], and any legal actions arising out of or in connection with this Contract shall be brought in the state courts located in [County].IN WITNESS WHEREOF, the parties have executed this Contract as of the date first above written.Homeowner:[Homeowner's Name][Homeowner's Address][Homeowner's Contact Information]Contractor:[Contractor's Name][Contractor's Address][Contractor's Contact Information]Schedule A – Renovation Services and Pricing[Include a detailed list of the renovation services, materials, and pricing information for the Work to be performed.]。

建筑装饰工程施工合同Construction & Decoration Work Contract工程名称：Project name: 工程地址：Project location: 发包方(甲方)： Owner (Party A): (Hereinafter referred to as Party A) 承包方(乙方)：Contractor (Party B): (hereinafter called Party B) 依照《中华人民共和国合同法》、《建筑装饰装修管理规定》、《住宅室内装饰装修管理办法》、《建筑安装工程承包合同条例》和国家工商行政管理局、建设部颁发的《建筑工程施工合同示范文本》（GB-91-0201）及有关法律、法规规定，就本项装修工程有关事项，经双方协商达成如下协议，以昭信守：In accordance with the PRC Contract Law, Administration Rules of Decoration of Civil Engineering, Administration Rules For Indoor Home Decoration, Construction Installation Engineering Contract Regulations and Construction & Project Works Contract Standard Form(GB-91-0201) issued by the National Commerce & Administration Board & Construction Department, and relevant laws, regulations and rules, the parties reach the following agreement in witnessthereof for this project. 第一条工程概况 Outline of Contract Work 1、工程名称： Project name: 2、工程地址： Project location: 3、承包方式：总承包（包工包料，包质量，包安全，包工期） Means of Contract: General Contract (Supply of materials & labor, Quality control, Safety control and schedule control). 4、承包内容：包括所有的拆除及改造工程，以附件《工程报价单》为准。

装修合同样本英文版Renovation ContractThis Agreement (hereinafter referred to as the "Contract") is made and entered into on this [date] day of [month], [year] (hereinafter referred to as the "Effective Date"), by and between:[Client's Name] (hereinafter referred to as the "Client"), residing at [Client's Address]AND[Contractor's Name] (hereinafter referred to as the "Contractor"), residing at [Contractor's Address]1. Scope of Work:a. Demolition of existing structures and removal of debris (if applicable)b. Construction and installation of new structures per the provided plans and specificationsc. Electrical, plumbing, and mechanical works as requiredd. Finishing works including painting, flooring, and related works2. Project Cost:With regards to the Project, the Total Project Cost is estimated to be [amount in currency] (hereinafter referred to as the "Contract Price"). The Client shall pay the Contractor an initial deposit of [amount in currency] (hereinafter referred to as the "Deposit") upon the signing of this Contract. The remaining balance shall be paid as follows: [payment schedule].3. Project Timeline:4. Change Orders:5. Permits and Approvals:The Contractor shall obtain all necessary permits and approvals required for the Project. The Client agrees to provide any necessary documentation or assistance required for this purpose.6. Warranty:7. Insurance:8. Termination:9. Governing Law:This Contract shall be governed by and construed in accordance with the laws of [State/Country]. Any disputesarising out of or in connection with this Contract shall be resolved through negotiation between the parties. In the eventof failure to reach a resolution, both parties agree to submit to the exclusive jurisdiction of the courts of [State/Country].10. Entire Agreement:This Contract constitutes the entire agreement between the Client and the Contractor, superseding all prior oral or written agreements. Any modifications to this Contract must be made in writing and signed by both parties.IN WITNESS WHEREOF, the Client and the Contractor have executed this Renovation Contract as of the Effective Date.[Client's Name][Client's Signature][Date][Contractor's Name][Contractor's Signature]。

中英文装修施工合同范本Contract for Interior Decoration Project合同日期： ________________Contract Date:甲方(委托方)：______________Party A (Client):乙方(承包方)：______________Party B (Contractor):鉴于甲方委托乙方进行装修施工，双方经友好协商达成如下协议：Whereas Party A entrusts Party B to carry out the interior decoration project, both parties have reached the following agreement through friendly negotiations:一、工程内容及标准：1. Project Details and Standards:1.1 甲方委托乙方进行_________（具体工程内容）装修施工，包括但不限于房屋结构改造、墙面装饰、地面铺设、水电安装等。

Party A entrusts Party B to carry out the interior decoration project, including but not limited to structural modification, wall decoration, flooring, plumbing and electrical installation.1.2 装修工程应符合国家相关标准和规定，保证工程质量。

The decoration project shall comply with the relevant national standards and regulations, and ensure the quality of the project.二、施工期限：2. Construction Period:2.1 本合同自签订之日起生效，工程施工期限为_______天。

全面版的室内设计合同英文版Comprehensive Interior Design ContractThis document serves as a comprehensive agreement between the client and the interior designer for the design and implementation of interior spaces. The contract outlines the rights and responsibilities of both parties to ensure a smooth and successful design process.Services ProvidedThe interior designer agrees to provide the following services:- Initial consultation to discuss client needs and preferences- Development of design concepts and mood boards- Selection of furnishings, materials, and accessories- Coordination with contractors and vendors- Installation and styling of final designClient ResponsibilitiesThe client agrees to:- Provide accurate information about their needs and budget- Make timely decisions on design options- Approve final design plans and budget- Provide access to the space for measurements and installations- Communicate any concerns or changes promptlyPayment TermsThe client agrees to pay the interior designer a fee of [insert amount] for the design services provided. Payment will be made in installments as outlined in the contract. Additional fees for materials, furnishings, and contractor services will be the responsibility of the client.TimelineThe interior designer will provide a timeline for the design process, including key milestones and deadlines. The client agrees to adhere to the timeline and provide any necessary approvals or feedback in a timely manner to avoid delays.TerminationEither party may terminate the contract with written notice if there is a breach of contract or if the project cannot be completed forunforeseen reasons. In the event of termination, the client will be responsible for payment of any services rendered up to the termination date.ConfidentialityBoth parties agree to keep all project-related information confidential, including design plans, budgets, and client preferences. Any disclosure of confidential information without consent may result in legal action.Governing LawThis contract shall be governed by the laws of [insert jurisdiction] and any disputes shall be resolved through arbitration. Both parties agree to comply with all legal requirements and regulations in the execution of this contract.By signing below, both parties acknowledge and agree to the terms and conditions outlined in this comprehensive interior design contract._______________________ _______________________Client Signature Designer Signature Date: _______________ Date: _______________。

全篇的房屋装修协议书英文版Full House Renovation AgreementThis document serves as a legally binding agreement between the homeowner, [Name], and the renovation contractor, [Company Name]. The purpose of this agreement is to outline the terms and conditions of the renovation project for [Address].1. Scope of Work:- The contractor agrees to renovate the following areas of the house: [List of specific areas].- The homeowner agrees to provide access to the property for the duration of the renovation.2. Timeline:- The renovation project is expected to be completed within [Number] weeks from the start date.- Delays may occur due to unforeseen circumstances, but the contractor will provide regular updates on the progress.3. Payment:- The total cost of the renovation is [Amount] and will be paid in installments as follows: [Payment schedule].- Any additional work requested by the homeowner will incur extra charges, to be agreed upon in writing.4. Materials and Labor:- The contractor will provide all necessary materials for the renovation, unless otherwise specified.- Labor costs are included in the total cost of the renovation and will be carried out by skilled professionals.5. Changes and Modifications:- Any changes or modifications to the original scope of work must be agreed upon in writing by both parties.- Changes may result in additional costs and/or extended timeline for completion.6. Warranty:- The contractor guarantees the quality of workmanship for a period of [Number] years from the completion date.- Any defects or issues arising from the renovation will be rectified by the contractor at no extra cost to the homeowner.7. Termination:- Either party may terminate this agreement with written notice if the other party breaches the terms outlined herein.- In the event of termination, the homeowner will be responsible for payment of work completed up to the termination date.8. Governing Law:- This agreement shall be governed by the laws of [State/Country] and any disputes shall be resolved through arbitration.By signing below, both parties acknowledge and agree to the terms and conditions of this house renovation agreement.Homeowner Signature: ________________________ Date:___________Contractor Signature: ________________________ Date: ___________。